Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.
Additional Compliance If any Proposed Key Holder Transfer is not consummated within forty-five (45) days after receipt of the Proposed Transfer Notice by the Company, the Key Holders proposing the Proposed Key Holder Transfer may not sell any Transfer Stock unless they first comply in full with each provision of this Section 2. The exercise or election not to exercise any right by any Investor hereunder shall not adversely affect its right to participate in any other sales of Transfer Stock subject to this Section 2.2.
Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Certificate of Occupancy 16.01 Tenant will at no time use or occupy the Premises in violation of the certificate of occupancy issued for the Building. The statement in this Lease of the nature of the business to be conducted by Tenant shall not be deemed to constitute a representation or guaranty by Landlord that such use is lawful or permissible in the Premises under the certificate of occupancy for the Building.
