CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. The Architect, upon a finding of defect or failure to conform, shall immediately notify the State and Contractor, in writing, of the defect. The Contractor shall begin correcting the defective or non-conforming Work within ten (10) days unless the State agrees to a Change Order which reflects the reduction in Contract Sum due to the value of diminishment of the defective or nonconforming Work.
Coordination of Work Licensee shall be responsible for coordination of its Equipment installation work to avoid any interference with existing utilities, substructures, facilities and/or SFMTA transit operations. Licensee shall be the City's point of contact for all Equipment installation and except in case of emergency, all communications concerning Equipment installation shall be through Licensee's field representatives.
Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.
Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.
Completion of Work Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order.
Performance of Work All work described in this Section 8 shall be performed only by Landlord or by contractors and subcontractors approved in writing by Landlord and only in accordance with plans and specifications approved by Landlord in writing. If Landlord elects, in its sole discretion, to supervise any work described in this Section 8, Tenant shall pay to Landlord a construction management fee equal to 5% of the cost of such work. Tenant shall cause all contractors and subcontractors to procure and maintain insurance coverage naming Landlord, Landlord’s Mortgagee, Landlord’s property management company and Landlord’s asset management company as additional insureds against such risks, in such amounts, and with such companies as Landlord may reasonably require. Tenant shall provide Landlord with the identities, mailing addresses and telephone numbers of all persons performing work or supplying materials prior to beginning such construction and Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable Laws. All such work shall be performed in accordance with all Laws and in a good and workmanlike manner so as not to damage the Building (including the Premises, the Building’s Structure and the Building’s Systems) and shall use materials of a quality that is at least equal to the quality designated by Landlord as the minimum standard for the Building, and in such manner as to cause a minimum of disruption to the other occupants of the Project and interference with other construction in progress and with the transaction of business in the Project and the related complex. Landlord may designate reasonable rules, regulations and procedures for the performance of all such work in the Building (including insurance requirements for contractors) and, to the extent reasonably necessary to avoid disruption to the occupants of the Building, shall have the right to designate the time when such work may be performed. All such work which may affect the Building’s Structure or the Building’s Systems must be approved by the Project’s engineer of record, at Tenant’s expense and, at Landlord’s election, must be performed by Landlord’s usual contractor for such work. All work affecting the roof of the Building must be performed by Landlord’s roofing contractor and no such work will be permitted if it would void or reduce or otherwise adversely affect the warranty on the roof. Upon completion of any work described in this Section 8, except with respect to any Permitted Alterations or any repairs required to be made by Tenant under Section 8.2, Tenant shall furnish Landlord with accurate reproducible “as-built” CADD files of the improvements as constructed.
Suspension of Work and Termination OWNER May Suspend Work:
PROTECTION OF WORK 12.1 Subcontractor shall effectually secure and protect the work done hereunder and assume full responsibility for the condition thereof until final acceptance by the OWNER and Contractor. Subcontractor further agrees to provide such protection as is necessary to protect the work and the workmen of Contractor, the OWNER, and other subcontractors from its operations.
Inspection of Work It is FIRST PARTY's obligation to make the work product available for CITY's inspections and periodic reviews upon request by CITY.
Continuation of Work Pending the resolution of any dispute or claim pursuant to this Article 11, the Parties agree that performance of all obligations will be pursued diligently.
