DELAYS BY COMPANY IN GRANTING APPROVALS Sample Clauses

DELAYS BY COMPANY IN GRANTING APPROVALS. In the event COMPANY --------------------------------------- fails to respond to any Design Documents within the time period prescribed by Section 5.6.2 or delays in granting or denying its approval beyond the time ------------- period prescribed by Section 9.2 or COMPANY'S Inspector fails to approve or ----------- disapprove inspected materials within the time period prescribed by Section 11.6 ------------ or COMPANY otherwise fails to grant or deny its consent or fails to approve or disapprove within any other time period prescribed by this Agreement, then (i) CONTRACTOR shall have the right to give COMPANY'S Representative (or COMPANY'S Inspector where COMPANY'S Inspector has caused the delay) 24-hours notice of such failure, and (ii) if COMPANY'S failure continues beyond one working day after receipt of said 24-hour notice, (a) COMPANY shall pay all additional costs incurred by CONTRACTOR as a result of COMPANY'S delay if (but only if) COMPANY'S delay affected the critical path set forth in the Project Schedule and the Budgeted Cost of the Work set forth in the then current Project Budget shall be adjusted, and (b) if COMPANY'S delay affects the critical path set forth in the then current Project Schedule, CONTRACTOR shall obtain an extension of the then current Project Schedule pursuant to Section 14.3 above. ------------
Sample 1
AutoNDA by SimpleDocs

Related to DELAYS BY COMPANY IN GRANTING APPROVALS

  • Non-Contravention of Existing Instruments; No Further Authorizations or Approvals Required None of the Parent Guarantor, the Issuer nor any of the subsidiaries of the Issuer is in violation of its charter or by-laws or other similar constitutive documents, except, in the case of subsidiaries of the Issuer, for such violations as would not, individually or in the aggregate, result in a Material Adverse Change. None of the Parent Guarantor, the Issuer nor any of the subsidiaries of the Issuer is in default (or, with the giving of notice or lapse of time or both, would be in default) (“Default”) under any indenture, mortgage, loan or credit agreement, note, contract, franchise, lease or other instrument to which the Parent Guarantor, the Issuer or any of the subsidiaries of the Issuer is a party or by which it or any of them may be bound, or to which any of the property or assets of the Parent Guarantor, the Issuer or any of the subsidiaries of the Issuer is subject (each, an “Existing Instrument”), except for such Defaults as would not, individually or in the aggregate, result in a Material Adverse Change. The Parent Guarantor’s and the Issuer’s execution, delivery and performance of this Agreement and the Indenture, and the respective execution, issuance and delivery of the Debt Securities and the Guarantees, the consummation of the transactions contemplated hereby, by the Indenture and by the Disclosure Package and the Prospectus (i) have been duly authorized by all necessary corporate or other action, as the case may be, and will not result in any violation of the provisions of the charter or by-laws or other similar constitutive documents of the Parent Guarantor, the Issuer or any of the subsidiaries of the Issuer, except, in the case of subsidiaries of the Issuer that are not Significant Subsidiaries, for such violations as would not, individually or in the aggregate, materially adversely affect the Parent Guarantor’s or the Issuer’s ability to consummate the transactions contemplated by this Agreement or the Indenture, (ii) will not conflict with or constitute a breach of, or Default under, or result in the creation or imposition of any lien, charge or encumbrance upon any property or assets of the Parent Guarantor, the Issuer or any of the subsidiaries of the Issuer pursuant to, or require the consent of any other party to, any Existing Instrument, except for such conflicts, breaches, Defaults, liens, charges or encumbrances as would not, individually or in the aggregate, result in a Material Adverse Change or materially adversely affect the Parent Guarantor’s or the Issuer’s ability to consummate the transactions contemplated by this Agreement or the Indenture and (iii) will not result in any violation of any law, administrative regulation or administrative or court decree applicable to the Parent Guarantor, the Issuer or any of the subsidiaries of the Issuer, except for such violation as would not, individually or in the aggregate, result in a Material Adverse Change or materially adversely affect the Parent Guarantor’s or the Issuer’s ability to consummate the transactions contemplated by this Agreement or the Indenture. No consent, approval, authorization or other order of, or registration or filing with, any court or other governmental or regulatory authority or agency, is required for the Parent Guarantor’s or the Issuer’s execution, delivery and performance of this Agreement or the Indenture, or the execution, issuance and delivery of the Debt Securities or the Guarantees or the consummation of the transactions contemplated hereby or thereby and by the Disclosure Package and the Prospectus, except such as have been obtained or made by the Parent Guarantor or the Issuer and are in full force and effect under the Securities Act, the Trust Indenture Act and applicable state securities or blue sky laws and from the Financial Industry Regulatory Authority (“FINRA”) or the failure of which to obtain would not have a material adverse effect on the consummation of the transactions contemplated by this Agreement or the Indenture.

  • Regulatory Consents and Approvals All consents, approvals and actions of, filings with and notices to any Governmental or Regulatory Authority necessary to permit the parties to this Agreement to perform their obligations under it and to consummate the transactions contemplated hereby, (a) shall have been duly obtained, made or given, (b) shall be in form and substance reasonably satisfactory to EPI, (c) shall not be subject to the satisfaction of any condition that has not been satisfied or waived and (d) shall be in full force and effect, and all terminations or expirations of waiting periods imposed by any Governmental or Regulatory Authority necessary for the consummation of the transactions contemplated by this Agreement, including under competition laws, shall have occurred.

  • Consents and Requisite Governmental Approvals; No Violations (a) No consent, approval or authorization of, or designation, declaration or filing with, any Governmental Entity is required on the part of TopCo or Merger Sub with respect to TopCo and Merger Sub’s execution, delivery or performance of its obligations under this Agreement or the Ancillary Documents to which it is or will be party or the consummation of the transactions contemplated hereby or by the Ancillary Documents, except for (i) the filing with the SEC of (A) the Registration Statement/Proxy Statement and the declaration of the effectiveness thereof by the SEC and (B) such reports under Section 13(a) or 15(d) of the Exchange Act as may be required in connection with this Agreement, the Ancillary Documents or the transactions contemplated by hereby or thereby, (ii) such filings with and approvals of Nasdaq to permit TopCo Ordinary Shares to be issued in accordance with this Agreement to be listed on Nasdaq, (iii) filing of the Merger Documents under the applicable law of the Cayman Islands, (iv) the approval and consent to be obtained by Merger Sub pursuant to Section 6.9, or (v) any consents, approvals, authorizations, designations, declarations, waivers or filings, the absence of which would not reasonably be expected to have a Company Material Adverse Effect.

  • Approvals, Consents and Waivers Each Group Company shall have obtained any and all approvals, consents and waivers necessary for consummation of the transactions contemplated by this Agreement, including, but not limited to, (i) all permits, authorizations, approvals, consents or permits of any governmental authority or regulatory body, and (ii) the waiver by the existing shareholders of the Company of any anti-dilution rights, rights of first refusal, preemptive rights and all similar rights in connection with the issuance of the Purchased Shares at the Closing.

  • Statutory Approvals No declaration, filing or registration with, or notice to or authorization, consent or approval of, any federal, state, local or foreign government, any instrumentality, subdivision, court, administrative agency or commission or authority thereof, or any quasi-governmental or private body exercising any regulatory, taxing, importing or other governmental or quasi-governmental authority or regulatory body (including a stock exchange or other self-regulatory body) or any other authority (each, a "Governmental Authority") is necessary for the execution and delivery of this Agreement by ITI or the consummation by ITI of the transactions contemplated hereby, except for those required under or in relation to (A) state securities or "blue sky" laws (the "Blue Sky Laws"), (B) the Securities Act, (C) the Exchange Act of 1934, as amended (the "Exchange Act"), (D) the DGCL with respect to the filing of the Certificate of Merger, (E) the ITI Stockholders' Consent, and (F) such consents, approvals, order, authorizations, registrations, declarations and filings the failure to obtain, make or give which would reasonably be expected to have, in the aggregate, an ITI Material Adverse Effect (the "ITI Required Statutory Approvals"), it being understood that references in this Agreement to "obtaining" such ITI Required Statutory Approvals shall mean making such declarations, filings or registrations; giving such notice; obtaining such consents or approvals; and having such waiting periods expire as are necessary to avoid a violation of law.

  • Regulatory Approvals; No Defaults (a) No consents or approvals of, or waivers by, or filings or registrations with, any Governmental Authority are required to be made or obtained by HCBF or any of its Subsidiaries in connection with the execution, delivery or performance by HCBF of this Agreement or to consummate the transactions contemplated by this Agreement, except as may be required for (i) filings of applications and notices with, and receipt of consents, authorizations, approvals, exemptions or nonobjections from, the SEC, NASDAQ, state securities authorities, the Financial Industry Regulatory Authority, Inc., applicable securities, commodities and futures exchanges, and other industry self-regulatory organizations (each, an “SRO”), (ii) filings of applications or notices with, and consents, approvals or waivers by the FRB, the FDIC and applicable state banking agencies, the Office of the Comptroller of the Currency (the “OCC”), the Florida Office of Financial Regulation (the “FOFR”) and other banking, regulatory, self-regulatory or enforcement authorities or any courts, administrative agencies or commissions or other Governmental Authorities and approval of or non-objection to such applications, filings and notices (taken together with the items listed in clause (i), the “Regulatory Approvals”), (iii) the filing with the SEC of the Proxy Statement-Prospectus and the Registration Statement and declaration of effectiveness of the Registration Statement, (iv) the filing of the Articles of Merger and the filing of documents with the OCC, applicable Governmental Authorities, and the Secretary of State of the State of Florida to cause the Bank Merger to become effective and (v) such filings and approvals as are required to be made or obtained under the securities or “Blue Sky” laws of various states in connection with the issuance of the shares of CenterState Common Stock pursuant to this Agreement and approval of listing of such CenterState Common Stock on the NASDAQ. Subject to the receipt of the approvals referred to in the preceding sentence and the Requisite HCBF Shareholder Approval, the execution, delivery and performance of this Agreement and the consummation of the transactions contemplated hereby by HCBF do not and will not (1) constitute a breach or violation of, or a default under, the articles of incorporation, bylaws or similar governing documents of HCBF or any of its respective Subsidiaries, (2) violate any statute, code, ordinance, rule, regulation, judgment, order, writ, decree or injunction applicable to HCBF or any of its Subsidiaries, or any of their respective properties or assets, (3) conflict with, result in a breach or violation of any provision of, or the loss of any benefit under, or a default (or an event which, with or without notice or lapse of time, or both, would constitute a default) under, result in the creation of any Lien under, result in a right of termination or the acceleration of any right or obligation under any permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, contract, franchise, agreement or other instrument or obligation of HCBF or any of its Subsidiaries or to which HCBF or any of its Subsidiaries, or their respective properties or assets is subject or bound, or (4) require the consent or approval of any third party or Governmental Authority under any such Law, rule or regulation or any judgment, decree, order, permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, contract, franchise, agreement or other instrument or obligation.

  • Regulatory Filings and Approvals Copies of all necessary governmental and third party approvals, registrations, and filings in respect of the transactions contemplated by this Agreement;

  • Government Approvals and Required Consents The Company, the Stockholders, NewCo and APP shall have obtained all licenses, permits and all necessary government and other third-party approvals and consents required under any law, statements, rule, regulation or ordinance to consummate the transactions contemplated by this Agreement.

  • Gaming Approvals If a Gaming Approval Failure occurs, then this Agreement shall automatically terminate. Each Party shall use good faith, commercially reasonable efforts in order to timely obtain the Requisite Gaming Approvals that it must obtain for the Call Right Transaction, and the other Party shall use good faith, commercially reasonable efforts in order to assist such Party in its efforts to timely obtain such Requisite Gaming Approvals. If there is a dispute among the Parties as to whether good faith, commercially reasonable efforts were used throughout the Regulatory Period, such dispute shall be resolved in accordance with the procedures set forth in Section 6 hereof, and such matter shall be submitted to arbitration in accordance with the procedures set forth in Section 6 hereof within twenty (20) days after the expiration of the Regulatory Period. Each Party, at no material unreimbursed expense to such Party, agrees to reasonably cooperate with the other Party and use commercially reasonable efforts to provide Regulatory Approval Supporting Information that is reasonably requested by the other Party, in such Party’s efforts to obtain any necessary regulatory approvals (including, if necessary, Requisite Gaming Approvals).

  • Regulatory Approvals All Requisite Regulatory Approvals shall have been obtained and shall remain in full force and effect and all statutory waiting periods in respect thereof shall have expired, and no such Requisite Regulatory Approval shall have resulted in the imposition of any Materially Burdensome Regulatory Condition.

Time is Money Join Law Insider Premium to draft better contracts faster.