Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.
Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.
Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.
Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
WORK LETTER This Lease is supplemented by that certain Work Letter of even date executed by Lessor and Lessee, attached hereto as Exhibit C, and incorporated herein by this reference.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
