Tenant Change Orders. If Tenant shall desire any changes to the Expansion Improvements, Tenant shall so advise Landlord in writing and Landlord shall determine whether such changes can be made in a reasonable and feasible manner. Any and all costs of reviewing any requested changes, and any and all costs of making any changes to the Expansion Improvements that Tenant may request and that Landlord may agree to, shall be at Tenant’s sole cost and expense and if Landlord requests, shall be paid to Landlord upon demand and before execution of the change order.
Tenant Change Orders. Except for changes called for or required due to the wrongful orgrossly negligent acts or deliberate omissions of Landlord, General Contractor, or Professional Service Providers or anyone for whom they are responsible, if Tenant shall desire any changes to the Final Working Drawings that are either (i) after such drawings are approved by Xxxxxx, or (ii) prior to the approval of Final Working Drawings, but reflect changes from the Final Plan, Tenant shall so advise Landlord in writing and Landlord shall determine whether such changes can be made in a reasonable and feasible manner and Landlord shall notify Tenant within five (5) Business Days of receipt of such notification, whether the change order process itself will result in a Tenant Delay. Landlord shall prepare and submit (as soon as reasonably practical but not exceeding five (5) Business Days) to Tenant a change order form (each, a “Change Order Form”) setting forth the impact on cost and any delay in the Project Schedule resulting from the proposed change. Tenant shall, within five (5) Business Days following Xxxxxx's receipt of such Change Order Form, either (A) execute and return the Change Order Form to Landlord (such executed Change Order form referred to herein as a “Tenant Change Order”), or (B) retract or modify its request for the change. In the event Tenant does not respond within such five (5) Business Day period, Tenant shall be deemed to have retracted its request for the change. Tenant may pay any costs associated with such Tenant Change Order by: (a) direct payment to Landlord, or (b) if the Allowable Construction Costs (defined in Schedule ) are less than the amount set forth in the Final Budget, application by Tenant of the savings to such costs. Within thirty (30) days following final determination of the Actual Costs, Tenant shall elect how to pay such costs. Landlord may not approve change orders without Xxxxxx’s consent with respect to the Landlord Work. Notwithstanding anything herein to the contrary, in no event shall Tenant be required to pay for, nor shall a Tenant Delay result from, any change order required due to the (i) failure of the Premises (including the Landlord Work) to comply with Legal Requirements, unless such failure is due to Legal Requirements triggered by any Tenant-Made Alterations or Tenant’s Property not reasonably discernible from the Final Working Drawings, (ii) the correction of errors or omissions in the Final Working Drawings, or (iii) any defects or...
Tenant Change Orders. Tenant’s request for changes to the Work or Change Orders under ¶ 8 or otherwise;
Tenant Change Orders. The Working Drawings and Specifications define the entire scope of Landlord's obligation to construct or provide the Leasehold Improvements. Subject to this Paragraph, Landlord shall make additions or changes to the Working Drawings and Specifications requested by Tenant ("Tenant Change Orders"). Tenant shall advise Landlord regarding any Tenant Change Orders in writing. All reasonable costs of reviewing any Tenant Change Orders, and any and all costs of making any such change shall be at Tenant's sole cost and expense, and shall be paid pursuant to Paragraph 5 of this Leasehold Improvement Work Letter. Such costs shall include, without limitation, costs of architects, engineers and consultants in reviewing and designing any such changes and the costs of contractors implementing such changes. When Landlord requests Tenant to provide specific information regarding any Tenant Change Orders, Tenant shall respond promptly so as not to delay Substantial Completion of the Leasehold Improvements on or before the Target Completion Date.
Tenant Change Orders. From time to time solely at its cost, Tenant may make changes to the Space Plan or the Working Drawings and Specifications and, in addition, to Tenant Improvement already installed ("Tenant Change Orders"). Tenant may not request changes to the Base Building without Landlord's prior written consent.
Tenant Change Orders. If Tenant shall desire any changes to the Third Expansion Improvements, Tenant shall so advise Landlord in writing and Landlord shall determine whether such changes can be made in a reasonable and feasible manner. Any and all costs of reviewing any requested changes, and any and all costs of making any changes to the Third Expansion Improvements that Tenant may request and that Landlord may agree to, shall be at Tenant’s sole cost and expense and if Landlord requests, shall be paid to Landlord upon demand and before execution of the change order.
Tenant Change Orders. (a) Tenant may, from time to time, after Tenant’s approval of the Base Building Construction Documents, request that changes be made to the Base Building Improvements which have not been Substantially Completed (each, a “Tenant Change Order”). Any Tenant Change Order requested by Tenant shall be in writing and shall identify the proposed change to the Base Building Construction Documents with reasonable specificity. Tenant hereby acknowledges and agrees that even a request for a Tenant Change Order may cause Landlord to incur out-of-pocket costs and expenses payable to third parties in order to evaluate the proposed Tenant Change Order (the “Evaluation Costs”) and may cause a delay in the performance of the Base Building Improvements and/or delay the Target Completion Date (an “Evaluation Delay”). Landlord shall use commercially reasonable efforts to incorporate into the Base Building Improvements any Tenant Change Order; however, if, in Landlord’s reasonable judgment, Tenant’s desired changes to the Base Building Improvements (i) will adversely impact the appearance, marketability, function or safety of the Building, (ii) could reasonably be expected to cause a delay in the Target Completion Date, or (iii) will not comply with all Legal Requirements and Permitted Exceptions (subject, however, to Tenant’s right, at its sole cost and expense, to appeal, contest or seek appropriate waivers from such Legal Requirements), Landlord reserves the right to disapprove any such Tenant Change Order.
Tenant Change Orders. See Section 3 below.
Tenant Change Orders. Except for changes called for or required due to the wrongful or negligent acts or omissions of Landlord, or anyone for whom Landlord is responsible, if a Tenant revision to the Initial Improvements will, as reasonably determined by Landlord, materially increase the cost of or time required to complete the Work, Landlord will determine whether such change can be made in a reasonable and feasible manner and Landlord will notify Tenant within five (5) Business Days of receipt of such notification, whether the change order process itself will result in a Tenant Delay. Landlord will prepare and submit (as soon as reasonably practical but not exceeding five (5) Business Days) to Tenant a change order form (each, a “Change Order Form”) setting forth the cost of Xxxxxx’s requested revision (the “Change Order Cost”) and any delay in the Target Date resulting from the proposed change. Tenant will, within five (5) Business Days following Xxxxxx’s receipt of such Change Order Form, either (i) execute and return the Change Order Form to Landlord (such executed Change Order form referred to herein as a “Tenant Change Order”), or (ii) retract or modify its request for the change. In the event Tenant does not respond within such five (5) Business Day period, Tenant will be deemed to have retracted its request for the change. Tenant shall pay Landlord the Change Order Cost within thirty (30) days of Substantial Completion of the Initial Improvements.
Tenant Change Orders. If Tenant desires any change in the Approved Plans or any work in addition to the Tenant Improvements in accordance with the Approved Plans to be performed in the Premises other than minor field adjustments ("Additional Tenant Work"), Tenant, at Tenant's expense, shall cause plans and specifications for such work to be prepared by Space Planner. All plans and specifications for Additional Tenant Work shall be subject to review and approval by Landlord (which shall not be unreasonably withheld, and which will be deemed disapproved if Landlord has not provided written notice of approval or disapproval (specifying the grounds for disapproval) within five (5) Business days following receipt) to ensure, among other things, that the work is compatible with all other construction and all electrical and mechanical systems within the Building. Landlord may charge Tenant all reasonable out-of-pocket, third-party costs actually and reasonably incurred by Landlord in connection with Landlord's review and processing of Tenant's change request (including, without limitation, space planners, architects, engineers), regardless of whether the requested change is ultimately approved by Landlord.
