Notice and Cure Period In the event of a breach, the aggrieved Party shall give written notice of breach to the other Party. If the notified Party does not cure the breach, at its sole expense, within 30 days after the delivery of written notice, the Party may exercise any of the remedies as described in §14 for that Party. Notwithstanding any provision of this Agreement to the contrary, the State, in its discretion, need not provide notice or a cure period and may immediately terminate this Agreement in whole or in part or institute any other remedy in the Agreement in order to protect the public interest of the State.
Cure Period Prior to any claim for default being made, either the Buyer or Seller will have an opportunity to cure any alleged default. If either Buyer or Seller fails to comply with any provision of this Agreement, the other party will deliver written notice to the non- complying party specifying such non-compliance. The non-complying party shall have calendar days after delivery of such notice to cure the non-compliance.
Notice and Cure In the event Seller or Purchaser fails to perform any of its obligations under this Agreement, the non-defaulting party shall provide the defaulting party with notice and five (5) days to cure such default, prior to pursuing any remedies available with respect to such default; provided, however, that (i) no such notice and cure shall be provided with respect to a party’s default in failing to timely close, or with respect to any party’s anticipatory breach of this Agreement, and (ii) in no event shall any such notice and cure period result in an extension of the Closing Date.
Notice and Cure Provisions Each party will give prompt notice to the other parties hereto of the occurrence, or failure to occur, at any time from the date hereof until the Closing Date, of any event or state of facts which occurrence or failure would or would be likely to:
Title Defects If: (i) the Title Commitment reflects any exceptions to title which are not acceptable to Buyer, in Buyer’s sole discretion; (ii) the Survey discloses any state of fact not acceptable to Buyer, in Buyer’s sole discretion; or (iii) at any time prior to the Closing, title to the Property is encumbered by any exception to title not acceptable to Buyer, in Buyer’s sole discretion (with any such exception or unacceptable state of fact being referred to herein as a “Title Defect”); then Buyer may, on or before the Satisfaction Date (or, in the case of a Title Defect not disclosed by the Title Commitment prior to the Satisfaction Date, within fifteen (15) days after Buyer receives notice of such Title Defect), provide Seller with written notice of such Title Defect. Seller shall have the right, but not the obligation (except as specifically set forth below), during the thirty (30) day period after receipt of such notice, but not later than the Closing, to remove such Title Defect or obtain affirmative title insurance coverage acceptable to Buyer, insuring and defending Buyer against any loss, cost, or expense arising out of or related to such Title Defect (“Affirmative Coverage”). If Seller elects to do so, then on or before the Closing Date (as defined below), Seller shall provide Buyer with reasonable evidence of such removal or provide reasonable evidence that such Title Defect will be removed or that such Affirmative Coverage will be obtained. Notwithstanding anything contained herein to the contrary, Seller shall be obligated to expend whatever sums are required to cure or obtain Affirmative Coverage for the following Title Defects prior to, or at, the Closing:
Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to:
Breach of Contract and Cure If either party breaches any of the covenants, promises, agreements, representations, and warranties provided by this Agreement, then the non-breaching party shall provide written notice of the breach to the address provided below for written notices under this Agreement by hand-delivery, U.S. Mail, commercial delivery service, such as Fed Ex or UPS, or fax, identifying the nature of the breach and providing the breaching party with ten (10) days from the delivery of the written notice to cure the breach. If the breaching party fails to cure the breach within ten (10) days of the delivery of the written notice of the breach, then the non-breaching party may terminate this contract for cause as set forth below and pursue any and all remedies for the breach available at law. If the District notifies Contractor that it is in breach of this Agreement, then the District may withhold all future payments to Contractor until any dispute regarding the breach of contract is resolved by the mutual, written agreement of the parties or by the entry of a final judgment by a court of law of competent subject matter jurisdiction and the resolution of any possible appeals from any such judgment. If the District withholds any payments to Contractor pursuant to this paragraph, then the District shall not be required to pay Contractor any amounts ultimately determined to be owed by the District to Contractor under this Agreement until any breach of contract dispute is resolved by the mutual, written agreement of the parties or by the entry of a final judgment by a court of law of competent subject matter jurisdiction and the resolution of any possible appeals from such judgment. Contractor further agrees that it may not charge interest on any payments withheld by the District pursuant to this paragraph until the breach of contract is resolved by the mutual, written agreement of the parties or by the entry of a final judgment by a court of law of competent subject matter jurisdiction and the resolution of any possible appeals from such judgment
Termination for Cause with Notice to Cure Requirement Contractor may terminate this contract for the Department’s failure to perform any of its duties under this contract after giving the Department written notice of the failure. The written notice must demand performance of the stated failure within a specified period of time of not less than 30 days. If the demanded performance is not completed within the specified period, the termination is effective at the end of the specified period.
Warranty Period Except as may be otherwise specified or agreed, Contractor shall repair all defects in materials, equipment, or workmanship appearing within one year from the date of Substantial Completion of the Work. If Substantial Completion occurs by phase, then the warranty period for that the Work performed for each phase begins on the date of Substantial Completion of that phase, or as otherwise stipulated on the Certificate of Substantial Completion for the particular phase.
RECTIFICATION OF DEFECTS 27.1 The Purchaser shall within 14 (fourteen) days after the Contractual Occupation Date notify the Seller in writing by way of a snaglist of all or any defects in the Unit, failing which the Purchaser shall be deemed to have accepted the Unit in good order and condition. Only ONE snaglist shall be considered. The Seller shall within a reasonable time thereafter at its cost repair all such defects and the Seller undertakes to rectify all latent and/or patent defects which become apparent to the Purchaser within 3 (three) calendar months from the Contractual Occupation Date and which is the result of defective materials and/or workmanship.
