Claims for Other Liability Sample Clauses

Claims for Other Liability. Except as provided in subsections 11.1(a) and (b), to the fullest extent permitted by law, Consultant shall hold harmless, defend (with counsel agreed to by City), and indemnify City and its officers, officials, agents, employees, and volunteers (collectively and/or individually “City”) from and against any and all liability, claim, loss, damage, expense, costs (including, without limitation, costs, attorneys’ fees, and expert fees of litigation) of every nature arising out of, related to, or in connection with the performance of work hereunder by Consultant or any of its officers, employees, servants, agents, or subcontractors, or the failure of the same to comply with any of the obligations contained in this Agreement, except such loss or damage which was caused by the sole negligence or sole willful misconduct of the City. Consultant’s duty to defend applies immediately, whether or not liability is established. An allegation or determination that persons other than Contractor are responsible for the claim does not relieve Contractor from its separate and distinct obligation to defend as stated herein.
Sample 1
AutoNDA by SimpleDocs
Claims for Other Liability. For all liabilities other than those included within paragraph A. above, Consultant shall, to the fullest extent allowed by law, indemnify, defend, and hold harmless the City and its officers, officials, agents, employees and volunteers against any and all liability, claims, actions, causes of action or demands whatsoever from and against any of them, including any injury to or death of any person or damage to property or other liability of any nature, that arise out of, pertain to, or relate to the performance of this Agreement by Consultant or Consultant's employees, officers, officials, agents or independent contractors. Such costs and expenses shall include reasonable attorneys’ fees of counsel of City’s choice, expert fees and all other costs and fees of litigation. Consultant shall not be obligated under this Agreement to indemnify City to the extent that the damage is caused by the sole or active negligence or willful misconduct of City, its agents or employees.
Sample 1
Claims for Other Liability. Consultant shall, to the fullest extent allowed by law, with respect to all services performed in connection with the Agreement indemnify, defend, and hold harmless the City and its officers, officials, agents, employees and volunteers from and against any and all liability, claims, actions, causes of action or demands whatsoever against any of them, including any injury to or death of any person or damage to property or other liability of any nature, that arise out of, pertain to, or relate to the performance of this Agreement by Consultant or Consultant's employees, officers, officials, agents or independent contractors. Such costs and expenses shall include reasonable attorneys’ fees of counsel of City’s choice, expert fees and all other costs and fees of litigation.
Sample 1

Related to Claims for Other Liability

  • Other Liability None of the Company Parties is responsible to You for any warranty provided by Company.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Other Liabilities Local Church represents and warrants that is has no loans, leases or other debts secured by the Real Property or Personal Property, except those matters set out Schedule 3.2, and that if any debts exist, secured or unsecured, it shall either satisfy all of its debts, loans, and liabilities, or assign or transfer such obligations to its new operating entity prior to or simultaneous with Closing, and solely bear the cost thereof. Local Church must provide sufficient documentation of the same to Annual Conference.

  • Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.

  • Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.

  • Cyber Liability identity theft insurance with a combined limit of Two Million Dollars ($2,000,000) per claim and Two Million Dollars ($2,000,000) general aggregate;

  • Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.

  • Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.

  • Customer Liability Customer is solely liable in respect of any loss or cost (including losses or costs suffered by third parties) due to goods not being stored or handled in accordance with this clause 8.

  • INDEMNIFICATION; LIABILITY a. To the fullest extent permitted by law, Contractor agrees to defend, indemnify, and hold the City, its officers, agents, and employees, harmless from and against any and all liabilities, demands, claims, suits, losses, damages, causes of action, fines or judgments, including costs, attorneys’, witnesses’, and expert witnesses’ fees, and expenses incident thereto, relating to, arising out of, or resulting from: (i) the services provided by Contractor personnel under this Agreement; (ii) any negligent acts, errors, mistakes or omissions by Contractor or Contractor personnel; and (iii) Contractor or Contractor personnel’s failure to comply with or fulfill the obligations established by this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.