Claim Notice A Party that seeks indemnity under this Article X (an "Indemnified Party") will give written notice (a "Claim Notice") to the Party from whom indemnification is sought (an "Indemnifying Party"), whether the Damages sought arise from matters solely between the Parties or from Third Party Claims. The Claim Notice must contain (i) a description and, if known, estimated amount (the "Claimed Amount") of any Damages incurred or reasonably expected to be incurred by the Indemnified Party, (ii) a reasonable explanation of the basis for the Claim Notice to the extent of facts then known by the Indemnified Party, and (iii) a demand for payment of those Damages. No delay or deficiency on the part of the Indemnified Party in so notifying the Indemnifying Party will relieve the Indemnifying Party of any liability for Damages or obligation hereunder except to the extent of any Damages caused by or arising out of such failure.
Notice of Direct Claims Any claim for indemnification or contribution under this Agreement or any Ancillary Agreement that does not result from a Third-Party Claim shall be asserted by written notice given by the Indemnitee to the applicable Indemnifying Party; provided, that the failure by an Indemnitee to so assert any such claim shall not prejudice the ability of the Indemnitee to do so at a later time except to the extent (if any) that the Indemnifying Party is prejudiced thereby. Such Indemnifying Party shall have a period of thirty (30) days after the receipt of such notice within which to respond thereto. If such Indemnifying Party does not respond within such thirty (30)-day period, such specified claim shall be conclusively deemed a Liability of the Indemnifying Party under this Section 4.6(b) or, in the case of any written notice in which the amount of the claim (or any portion thereof) is estimated, on such later date when the amount of the claim (or such portion thereof) becomes finally determined. If such Indemnifying Party does not respond within such thirty (30)-day period or rejects such claim in whole or in part, such Indemnitee shall, subject to the provisions of Article VII, be free to pursue such remedies as may be available to such party as contemplated by this Agreement and the Ancillary Agreements, as applicable, without prejudice to its continuing rights to pursue indemnification or contribution hereunder.
Advance Requests Borrower may request that Lender make an Advance by delivering to Lender an Advance Request therefor and Lender shall be entitled to rely on all the information provided by Borrower to Lender on or with the Advance Request. The Lender may honor Advance Requests, instructions or repayments given by the Borrower (if an individual) or by any Authorized Person.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Claim Decision Upon receipt of such claim, the Plan Administrator shall respond to such claimant within ninety (90) days after receiving the claim. If the Plan Administrator determines that special circumstances require additional time for processing the claim, the Plan Administrator can extend the response period by an additional ninety (90) days for reasonable cause by notifying the claimant in writing, prior to the end of the initial ninety (90) day period, that an additional period is required. The notice of extension must set forth the special circumstances and the date by which the Plan Administrator expects to render its decision. If the claim is denied in whole or in part, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.
Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
Notice of Loss; Third Party Claims (a) An Indemnified Party shall give the Indemnifying Party notice of any matter which an Indemnified Party has determined has given or could give rise to a right of indemnification under this Agreement, within 60 days of such determination, stating the amount of the Loss, if known, and method of computation thereof, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises.
Notice of Third Party Claims Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.
Direct Claim Any Direct Claim must be asserted by giving the Indemnitor Notice thereof, stating the nature of such claim in reasonable detail and indicating the estimated amount, if practicable. The Indemnitor will have a period of sixty (60) days from receipt of such Notice within which to respond to such Direct Claim. If the Indemnitor does not respond within such sixty (60) day period, the Indemnitor will be deemed to have accepted such Direct Claim. If the Indemnitor rejects such Direct Claim, the Indemnitee will be free to seek enforcement of its rights to indemnification under this Agreement.
