Continued Performance The Contractor and Contractor Parties shall continue to Perform their obligations under the Contract while any dispute concerning the Contract is being resolved.
Payment and Performance Bond Prior to the execution of this Contract, City may require Contractor to post a payment and performance bond (Bond). The Bond shall guarantee Contractor’s faithful performance of this Contract and assure payment to contractors, subcontractors, and to persons furnishing goods and/or services under this Contract.
Excused Performance 6.1 Notwithstanding the occurrence of a Force Majeure Event, in which case Clause 17 will govern, BT will not be liable for any failure or delay to perform any of its obligations under this Agreement (including any of its obligations to meet any Service Levels) to the extent that BT’s failure or delay in performing arises as a result of:
Payment and Performance Bonds The Contractor shall comply with the following minimum bonding requirements:
Assignment and Performance Neither this Agreement nor any right or interest herein shall be assigned, transferred, or encumbered without the written consent of the other party. In addition, Contractor shall not subcontract any portion of the Work required by this Agreement, except as provided in the Schedule of Subcontractor Participation. City may terminate this Agreement, effective immediately, if there is any assignment, or attempted assignment, transfer, or encumbrance, by Contractor of this Agreement or any right or interest herein without City’s prior written consent. Contractor represents that each person who will render services pursuant to this Agreement is duly qualified to perform such services by all appropriate governmental authorities, where required, and that each such person is reasonably experienced and skilled in the area(s) for which he or she will render his or her services. Contractor shall perform Contractor’s duties, obligations, and services under this Agreement in a skillful and respectable manner. The quality of Contractor’s performance and all interim and final product(s) provided to or on behalf of City shall be comparable to the best local and national standards. In the event Contractor engages any subcontractor in the performance of this Agreement, Contractor shall ensure that all of Contractor’s subcontractors perform in accordance with the terms and conditions of this Agreement. Contractor shall be fully responsible for all of Contractor’s subcontractors’ performance, and liable for any of Contractor’s subcontractors’ non-performance and all of Contractor’s subcontractors’ acts and omissions. Contractor shall defend at Contractor’s expense, counsel being subject to City’s approval or disapproval, and indemnify and hold City and City’s officers, employees, and agents harmless from and against any claim, lawsuit, third party action, fine, penalty, settlement, or judgment, including any award of attorney fees and any award of costs, by or in favor of any of Contractor’s subcontractors for payment for work performed for City by any of such subcontractors, and from and against any claim, lawsuit, third party action, fine, penalty, settlement, or judgment, including any award of attorney fees and any award of costs, occasioned by or arising out of any act or omission by any of Contractor’s subcontractors or by any of Contractor’s subcontractors’ officers, agents, or employees. Contractor’s use of subcontractors in connection with this Agreement shall be subject to City’s prior written approval, which approval City may revoke at any time.
DELIVERY AND PERFORMANCE All work performed under contracts or task orders will be at the highest quality applicable and delivered according to Statement of Objectives (SOO), Statement of Works (SOW), or Performance Work Statements (PWS). The Contractor must deliver and perform according to the requirements of the contract or task order, and may be denied further work for substandard performance. The Government may include deliveries or performance requirements, such as (1) optional clauses, (2) agency clauses, or (3) specific clauses, in a contract or task order.
Continuing Contract Performance Pending final resolution of a Claim including litigation, unless otherwise agreed in writing the Contractor shall proceed diligently with performance of the Contract and the Owner shall continue to make payments in accordance with the Contract Documents.
Bid and Performance Security The Contractor hereby and herewith deposits with and delivers to the Minister, as security of the due fulfilment of the Contract, one of the following, which shall remain in effect for a minimum of 30 days after tender closing:
Continuing Performance Each party is required to continue to perform its obligations under this contract pending final resolution of any dispute arising out of or relating to this contract, unless to do so would be impossible or impracticable under the circumstances.
Past Performance The Government will evaluate the contractor's performance on the NETCENTS-2 Orders provided in Exhibit B, CDRL B001. The PCO will determine the quality of the work performed based on an integrated assessment of data obtained in the Contractor Performance Assessment Reporting Systems (CPARS) and information obtained from Defense Contract Management Agency (DCMA) channels, interviews with customers, program managers and/or contracting officers for NETCENTS-2 task orders. Based on the contractor performance records above, the PCO will determine if there is an expectation that the contractor will successfully perform the required efforts under the unrestricted Application Services contract.
