Construction Manager The individual, partnership, corporation, joint venture, or any combination thereof, or its authorized representative, named as such by the District. If no Construction Manager is used on the Project that is the subject of this Contract, then all references to Construction Manager herein shall be read to refer to District.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Case Management Prompt resolution of any dispute is important to both parties; and the parties agree that the arbitration of any dispute shall be conducted expeditiously. The arbitrators are instructed and directed to assume case management initiative and control over the arbitration process (including scheduling of events, pre-hearing discovery and activities, and the conduct of the hearing), in order to complete the arbitration as expeditiously as is reasonably practical for obtaining a just resolution of the dispute.
Construction Management Property Manager shall be responsible for coordinating and facilitating the planning and the performance of all construction including, without limitation, all maintenance, repairs, capital improvements, common area refurbishments and Tenant Improvements required to be constructed by Company after the Effective Date (collectively, “Construction Projects”), regardless of whether or not any of the Construction Projects arises out of a Lease executed prior to the Effective Date. Such coordination and facilitation services shall include, for example and not by any way of limitation, retaining architects, engineers or other consultants, assisting in the development of repair, capital improvement or Tenant space plans, cost estimating, advising Company with respect to the need for a general contractor, construction manager or other consultant, posting of appropriate notices of non-responsibility, providing notices of construction to affected Tenants and mitigating the effects of construction on such Tenants, and providing contractors, vendors and other Construction Property related personnel with access to the Property, parking and staging areas, necessary utilities and services. Property Manager shall be responsible for conducting meetings as deemed reasonably necessary by Property Manager, with the architect, contractor and consultants for all Construction Projects. Property Manager will also prepare a written report to Company as deemed reasonably necessary regarding the progress of each Construction Property in a format to be approved by the Company.
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Seven Thousand, Nine Hundred Ninety-Seven Dollars and Eighty Cents ($7,997.80). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
Union-Management Committee There shall be a union/management committee comprised of four (4) employee representatives appointed by the Union and four (4) employer representatives. The Committee's purpose is to provide and promote effective and meaningful communication of information and ideas and to make joint recommendations on matters of concern. Matters that are properly the subject of an individual grievance will not be discussed at this committee. The Committee will meet quarterly, unless agreed otherwise, at a time and place mutually agreed to provided there is business for their joint consideration. The parties will exchange agenda items at least one (1) week prior to the meeting. The parties further agree the Committee may meet at any time its members mutually agree a meeting should be held. The duties of the Chairperson will be shared by the parties. Copies of the minutes shall be provided to Committee members. The employer agrees to pay for time spent during regular working hours for representatives of the union attending such meetings. The parties may utilize video or teleconferencing services for the purposes of committee members attending committee meetings, where appropriate and available. Neither party can unreasonably deny an initiative to utilize video or teleconferencing services.
Disease Management If you have a chronic condition such as asthma, coronary heart disease, diabetes, congestive heart failure, and/or chronic obstructive pulmonary disease, we’re here to help. Our tools and information can help you manage your condition and improve your health. You may also be eligible to receive help through our care coordination program. This voluntary program is available at no additional cost you. To learn more about disease management, please call (000) 000-0000 or 0-000-000-0000. About This Agreement Our entire contract with you consists of this agreement and our contract with your employer. Your ID card will identify you as a member when you receive the healthcare services covered under this agreement. By presenting your ID card to receive covered healthcare services, you are agreeing to abide by the rules and obligations of this agreement. Your eligibility for benefits is determined under the provisions of this agreement. Your right to appeal and take action is described in Appeals in Section 5. This agreement describes the benefits, exclusions, conditions and limitations provided under your plan. It shall be construed under and shall be governed by the applicable laws and regulations of the State of Rhode Island and federal law as amended from time to time. It replaces any agreement previously issued to you. If this agreement changes, an amendment or new agreement will be provided.
Utilization Management Case management means a care management plan developed for a Member whose diagnosis requires timely coordination. All benefits, including travel and lodging, are limited to Covered Services that are Medically Necessary and set forth in the EOC. KFHPWA may review a Member's medical records for the purpose of verifying delivery and coverage of services and items. Based on a prospective, concurrent or retrospective review, KFHPWA may deny coverage if, in its determination, such services are not Medically Necessary. Such determination shall be based on established clinical criteria and may require Preauthorization. KFHPWA will not deny coverage retroactively for services with Preauthorization and which have already been provided to the Member except in the case of an intentional misrepresentation of a material fact by the patient, Member, or provider of services, or if coverage was obtained based on inaccurate, false, or misleading information provided on the enrollment application, or for nonpayment of premiums.
Professional Development Committee There shall be a Professional Development Committee composed of two (2) members of the Association one of whom shall be the Bargaining Unit President or designate and two (2) representatives of the Hospital one of whom shall be the Chief Nursing Officer or designate and one human resources representative.
Local Professional Development Committee 1. The Local Professional Development Committee (LPDC) shall be established to oversee and review professional development plans pursuant to ORC 3319.22.