Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Contract Work Hours and Safety Standards Act The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS The undersigned (authorized official signing for the contracting organization) certifies that the contractor will, or will continue to, provide a drug-free workplace in accordance with 45 CFR Part 76 by:
Reporting of Sales to TIPS by Vendor The Participation Fee that was published as part of the Solicitation and the fee published is the legally effective fee, along with any fee conditions stated in the Solicitation. Collection of the fees by TIPS is required under Texas Government Code §791.011 Et seq. Fees are due on all TIPS purchases reported by either Vendor or Member. Fees are due to TIPS upon payment by the Member to the Vendor, Reseller or Vendor Assigned Dealer. Vendor, Reseller or Vendor Assigned Dealer agrees that the participation fee is due to TIPS for all Agreement sales immediately upon receipt of payment including partial payment, from the Member Entity and must be paid to TIPS at least on a monthly basis, specifically within 31 calendar days of receipt of payment, if not more frequently, or as otherwise agreed by TIPS in writing and signed by an authorized signatory of TIPS. Thus, when an awarded Vendor, Reseller or Vendor Assigned Dealer receives any amount of payment, even partial payment, for a TIPS sale, the legally effective fee for that amount is immediately due to TIPS from the Vendor and fees due to TIPS should be paid at least on a monthly basis, specifically within 31 calendar days of receipt of payment, if not more frequently. Reporting of Sales to TIPS by Vendor Vendor is required to report all sales under the TIPS contract to TIPS. When a public entity initiates a purchase with a TIPS Awarded Vendor, if the Member inquires verbally or in writing whether the Vendor holds a TIPS Contract, it is the duty of the Vendor to verify whether or not the Member is seeking a TIPS purchase. Once verified, the Vendor must include the TIPS Contract number on any communications and related sales documents exchanged with the TIPS Member entity. To report sales, the Vendor must login to the TIPS Vendor Portal online at xxxxx://xxx.xxxx-xxx.xxx/vendors_form.cfm and click on the PO’s and Payments tab. Pages 3-7 of the Vendor Portal User Guide will walk you through the process of reporting sales to TIPS. Please refer to the TIPS Accounting FAQ’s for more information about reporting sales and if you have further questions, contact the Accounting Team at xxxxxxxxxx@xxxx-xxx.xxx. The Vendor or vendor assigned dealers are responsible for keeping record of all sales that go through the TIPS Agreement and submitting same to TIPS. Failure to render the participation fee to TIPS shall constitute a breach of this agreement with our parent governmental entity, Texas Education Service Center Region 8, as established by the Texas legislature and shall be grounds for termination of this agreement and any other agreement held with TIPS and possible legal action. Any overpayment of participation fees to TIPS by a Vendor will be refunded to the Vendor within ninety (90) days of receipt of notification if TIPS receives written notification of the overpayment not later than the expiration of six (6) months from the date of overpayment and TIPS determines that the amount was not legally due to TIPS pursuant to this agreement and applicable law. It is the Vendor’s responsibility to identify which sales are TIPS Agreement sales and pay the correct participation fee due for TIPS Agreement sales. Any notification of overpayment received by TIPS after the expiration of six (6) months from the date of overpayment will be non-refundable. Region 8 ESC and TIPS reserve the right to extend the six (6) month deadline to notify if approved by the Region 8 ESC Board of Directors. TIPS reserves all rights under the law to collect the fees due. Please contact TIPS at xxxx@xxxx-xxx.xxx or call (000) 000-0000 if you have questions about paying fees.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
DECLARATION OF COMPLIANCE WITH APPLICABLE STANDARDS 1. Does the Work report experiments involving human subjects? [ ] YES [ ] NO If Yes, were the reported experiments in accordance with the ethical standards of the committee responsible for human experimentation (institutional and national), and with the Helsinki Declaration of 1975, as revised in 2013 (xxxx://xxxxxx.xxx.xxx/ecodes/node/3931 )? [ ] YES [ ] NO (If Yes, the Assignor must submit a copy of the approval and consent-to-disclose form to Xxxxxxx Science Publishers by fax or email.) Please state whether Ethical Approval was given, by whom and the relevant Judgement’s reference number. (If No, the Assignor must mention an institutional or regional guideline.) 2. Does the Work report experiments involving animals? [ ] YES [ ] NO If Yes, were the reported experiments in accordance with the standards set forth in one of below national guidelines and regulations: o The US National Research Council's "Guide for the Care and Use of Laboratory Animals," o The US Public Health Service's "Policy on Humane Care and Use of Laboratory Animals," and "Guide for the Care and Use of Laboratory Animals." o UK : the Animals (Scientific Procedures) Act 1986 Amendment Regulations (SI 2012/3039). [ ] YES [ ] NO 6 [v.122016] CONFLICTS OF INTEREST Conflicts of interest arise when authors, reviewers, or editors have interests (such as financial or personal interests) that are not made clear and that may influence their judgment on the content of their work. Authors and editors who submit work for publication with Xxxxxxx Science are required to disclose and acknowledge all forms of financial support relating to the work to be published, all commercial or financial involvement that might present an appearance of a conflict of interest in respect of the work, and all agreements relating to sponsorship of any research upon which the work is based. Are there any actual, or potential, conflicts of interest? [ ] YES [ ] NO If Yes, details of the actual or potential conflicts of interest must be set-out in the spaces provided below. DISCLOSURE REGARDING ACTUAL OR POTENTIAL CONFLICTS OF INTEREST: [INSERT] DISCLOSURE REGARDING THIRD PARTY FINANCIAL CONTRIBUTIONS: [INSERT] LANGUAGE AND EDITING: Does Assignor require assistance in having the English grammar and style of the Work checked and improved by Xxxxxxx Science? [ ] YES [ ] NO If Yes, Xxxxxxx Science will provide a quote in respect of the same.
Xxxxx-Xxxxx Act compliance IF proposing on PART 2, Texas Statute requires compliance with Xxxxx-Xxxxx Act, as amended (40 U.S.C. 3141- 3148). When required by Federal program legislation, all prime construction contracts in excess of $2,000 awarded by non-Federal entities must include a provision for compliance with the Xxxxx-Xxxxx Act (40 U.S.C. 3141-3144, and 3146-3148) as supplemented by Department of Labor regulations (29 CFR Part S, "Labor Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted Construction"). In accordance with the statute, contractors must be required to pay wages to laborers and mechanics at a rate not less than the prevailing wages specified in a wage determination made by the Secretary of Labor. In addition, contractors must be required to pay wages not less than once a week. The non-Federal entity must place a copy of the current prevailing wage determination issued by the Department of Labor in each solicitation. The decision to award a contract or subcontract must be conditioned upon the acceptance of the wage determination. The non-Federal entity must report all suspected or reported violations to the Federal awarding agency. The contracts must also include a provision for compliance with the Xxxxxxxx "Anti-Kickback" Act {40 U.S.C. 314S), as supplemented by Department of Labor regulations (29 CFR Part 3, "Contractors and Subcontractors on Public Building or Public Work Financed in Whole or in Part by Loans or Grants from the United States"). The Act provides that each contractor or subrecipient must be prohibited from inducing, by any means, any person employed in the construction, completion, or repair of public work, to give up any part of the compensation to which he or she is otherwise entitled. The non-Federal entity must report all suspected or reported violations to the Federal awarding agency. BY SUBMITTING A PROPOSAL FOR PART 2 OF THIS SOLICITATION, the Vendor agrees, AS REQUIRED BY LAW, to comply with the Xxxxx Xxxxx Act, IF APPLICABLE and if proposing on PART 2 of this solicitation.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Compliance with Xxxxx-Xxxxx and Related Act requirements All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.
