THE LEASE COMMENCEMENT DATE definition

THE LEASE COMMENCEMENT DATE means the 28th day after and excluding the Date of Practical Completion;
Sample 1Sample 2
THE LEASE COMMENCEMENT DATE means the earlier of (a) the date the work and materials to be provided pursuant to Exhibit B are deemed substantially complete as determined pursuant to Exhibit B, or (b) the date Tenant commences beneficial use of the Premises. Tenant shall be deemed to have commenced beneficial use of the Premises when Tenant begins to move furniture, furnishings, inventory, equipment or trade fixtures other than modular furniture into the Premises. If Tenant is in breach of any obligation hereunder, then Tenant shall not have any right to commence beneficial use of the Premises.
Sample 1

Examples of THE LEASE COMMENCEMENT DATE in a sentence

  • Landlord shall have access to the Premises for improvement of the Premises at all times subsequent to execution of this Lease until completion of punch list items.Landlord: (initial)Tenant: (initial) EXHIBIT C FORM OF CERTIFICATE AFFIRMING THE LEASE COMMENCEMENT DATE This Exhibit is attached to and made a part of that certain Lease Agreement dated as of September 8, 2020 (the "Lease"), by and between NextGen Holdings, LLC.

  • ACCORDINGLY, TENANT ACCEPTS POSSESSION OF THE PREMISES IN ITS “AS IS” CONDITION AS OF THE LEASE COMMENCEMENT DATE.

  • Approval for vacation/educational trip requests will be evaluated by the following standards: previous attendance records, previous requests, academic performance and the educational value of the activity.

  • For Apprentices who complete their Apprenticeship, Apprenticeship is a success.

  • The statewide Open Enrollment application is available at minnetonkaschools.org/k-enroll and should be returned as soon as possible or by January 15.

  • TENANT HEREBY ACCEPTS THE LEASED -------------------- PREMISES IN ITS "AS-IS" CONDITION EXISTING ON THE LEASE COMMENCEMENT DATE.

  • RENT FREE PERIOD NOTWITHSTANDING THE LEASE COMMENCEMENT DATE contained herein, the Tenant shall not be obliged to pay Minimum Rent during the first 4 months of the term, provided, however, that the Tenant shall be responsible to pay for all additional rent from the date of occupancy.

  • IN THE EVENT THE TENANT IMPROVEMENT DATE IS DELAYED BEYOND NOVEMBER 2, 2000, THE LEASE COMMENCEMENT DATE SHALL BE EXTENDED ONE DAY FOR EACH DAY THE TENANT IMPROVEMENT COMMENCEMENT DATE IS DELAYED.

  • LANDLORD MAKES NO REPRESENTATION OR WARRANTY THAT THE PREMISES ARE FIT OR ZONED FOR THE PERMITTED USE AND TENANT SHALL ACCEPT THE PREMISES UPON THE LEASE COMMENCEMENT DATE IN ITS “AS-IS” CONDITION.

  • ACCORDINGLY, LESSEE ACCEPTS POSSESSION OF THE DEMISED PREMISES IN ITS "AS IS" CONDITION AS OF THE LEASE COMMENCEMENT DATE (as defined in Section 2.1).

Related to THE LEASE COMMENCEMENT DATE

  • Lease Commencement Date has the meaning specified in Section 3.2 of the Master Lease.

  • Rent Commencement Date means [Insert date or description] or any later date calculated in accordance with paragraph 3.3 of Part 5 of the Schedule;

  • the commencement date means the date on which the Contract shall take effect, as notified by the Authority to the Contractor in a letter awarding the Contract.

  • Commencement Date means the date fourteen (14) days after the date the Contract comes into effect or any other date named in the Contract Data.

  • Service Commencement Date means the date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Tariff, Part II, section 15.3 or Tariff, Part III, section 29.1.

  • Billing Commencement Date means the earlier of:

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Loan Commencement Date means, with respect to each Loan, the first Business Day of the calendar month following the Funding Date of such Loan.

  • Pay Out Commencement Date means the date on which a Trust Pay Out Event is deemed to occur pursuant to Section 9.01 of the Agreement or a Series 2001-D Pay Out Event is deemed to occur pursuant to Section 7 hereof.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Payment Commencement Date means the date payments of amounts deferred begin pursuant to Article III, Section 6.

  • Employment Commencement Date means the date on which the Employee first performs an Hour of Service.

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Policy Commencement Date means the date of commencement of the Policy as specified in the Schedule.

  • Offering Commencement Date means the first day of each Offering Period.

  • commencement day means the day on which the State Administrative Tribunal (Conferral of Jurisdiction) Amendment and Repeal Act 2004 Part 2 Division 29 comes into operation;

  • Recommencement Date As defined in Section 6(d) hereof.

  • Services Commencement Date means the date delivery of the Services shall commence as specified in the Key Provisions. If no date is specified in the Key Provisions this date shall be the Commencement Date;

  • Vesting Commencement Date means the Grant Date or such other date selected by the Committee as the date from which an Award begins to vest.

  • Date of Commencement means the date designated in the Notice to Proceed for Contractor to commence the Work.

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Lease Period means each of the consecutive periods throughout the Basic Term and any Renewal Term ending on a Lease Period Date, the first such period commencing on and including the Delivery Date.

  • Annuity Commencement Date means the first day of any month upon which an annuity begins under the Contract. However, for any Participant, this date shall not be later than the required beginning date as defined in the applicable sections of the Code and Regulations issued thereunder.

  • Commencement Date of the Contract means the date of signing of the Contract between the Purchaser and the Contractor.

  • Term Commencement Date shall be the later of (i) November 1, 2006 or (ii) the date on which Landlord’s Work is Substantially Complete (or the date on which Landlord’s Work would have been Substantially Complete absent Tenant Delay or Force Majeure (as defined below)); provided, however, that if the Term Commencement Date is not the first day of a calendar month, then the first lease year shall be extended through the last day of the calendar month in which the first 12-month period expires, and Rent for the additional period at the end of the first lease year shall be payable at the rate for the 12th month of the Term. “Force Majeure” means accident; breakage; repair; governmental regulation, moratorium or other governmental action. The “Term Expiration Date” shall be the day immediately preceding the seventh (7th) anniversary of the Term Commencement Date, provided that if such preceding day is not the last day of a calendar month, then the Term Expiration Date shall be the last date of the calendar month in which such preceding day occurs. Landlord and Tenant shall each execute and deliver to the other written acknowledgment of the actual Term Commencement Date and the Term Expiration Date when such are established, and shall attach it to this Lease as Exhibit B. Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.