Environmental Requirement means any Environmental Law, agreement or restriction, as the same now exists or may be changed or amended or come into effect in the future, which pertains to health or safety (as they relate to natural resources or the environment), any Hazardous Material, or the environment, including ground, air, water or noise pollution or contamination, and underground or aboveground tanks.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Governmental Real Property Disclosure Requirements means any Requirement of Law of any Governmental Authority requiring notification of the buyer, lessee, mortgagee, assignee or other transferee of any Real Property, facility, establishment or business, or notification, registration or filing to or with any Governmental Authority, in connection with the sale, lease, mortgage, assignment or other transfer (including any transfer of control) of any Real Property, facility, establishment or business, of the actual or threatened presence or Release in or into the Environment, or the use, disposal or handling of Hazardous Material on, at, under or near the Real Property, facility, establishment or business to be sold, leased, mortgaged, assigned or transferred.
essential requirements means all the conditions set out in Annex III which must be met by the rail system, the subsystems, and the interoperability constituents, including interfaces;
Project specific information means such part of the Instructions to Consultants used to reflect specific project and assignment conditions.
Operational requirements means the need to ensure that the Agency is to be operated as effectively, efficiently and economically as possible.
Compliance schedule means a schedule of events, by date, which will result in compliance with these regulations.
Project Requirements means the statement included in the Request for Proposal detailing the technical and other requirements of Canada which are to be met by the successful Bidder, and which are to be addressed in the Bid;
Environmental Requirements means any legal requirement relating to health, safety or the environment and applicable to the Borrower, any Subsidiary or the Properties, including but not limited to any such requirement under CERCLA or similar state legislation and all federal, state and local laws, ordinances, regulations, orders, writs, decrees and common law.
Environmental Guidelines means the environmental guidelines and occupational health and safety standards of the World Bank Group as in effect on [Bid Date].
Environmental impact statement means a detailed written statement as required by section 102(2)(C) of the Act.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Time Schedule means the Time Schedule for final completion of the Works or Mechanical Completion of the Plant(s)/Unit(s) as the case may be, incorporated in the Contract or as may be extended by the OWNER or Engineer-in-Charge pursuant to the provisions hereof and shall include interim time schedules set up for achieving interim/phase-wise/stage-wise progress/completion/testing/commissioning/handing over, as may be prescribed by the OWNER/Engineer-in-Charge, within the overall Time Schedule as originally envisaged or as extended.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Specification Schedule means the Schedule containing details of the Specification.
Monitoring Requirements Schedule means the Schedule containing details of the monitoring arrangements.
Governmental Requirements means all federal, state, and local laws, statutes, ordinances, rules, regulations, orders, and decrees of any court, administrative body, or tribunal related to the activities and performances under this Agreement.
Environmental Compliance means actions performed during or after Operations to comply with the requirements of all Environmental Laws or contractual commitments related to reclamation of the Properties or other compliance with Environmental Laws.
Material safety data sheet or "MSDS" means the chemical, physical, technical, and safety information document supplied by the manufacturer of the coating, solvent, or other chemical product, usually through the distribution network or retailers.
Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.
Standard Specifications means a compilation in book form of specifica- tions approved for general application and repetitive use;
Governmental Requirement means any law, statute, code, ordinance, order, determination, rule, regulation, judgment, decree, injunction, franchise, permit, certificate, license, rules of common law, authorization or other directive or requirement, whether now or hereinafter in effect, of any Governmental Authority.
End Client Requirements means the specific requirements of the End Client, as notified to the Supplier in writing;
Equipment with Specific Operational Limits means any Equipment related to the thermal oxidation of waste or waste derived fuels, fume incinerators or any other Equipment that is specifically referenced in any published Ministry document that outlines specific operational guidance that must be considered by the Director in issuing of a Certificate of Approval.
MREL Requirements means the laws, regulations, requirements, guidelines, rules, standards and policies relating to minimum requirements for own funds and eligible liabilities applicable to the Issuer and/or the Group, from time to time, (including any applicable transitional or grandfathering provisions), including, without limitation to the generality of the foregoing, any delegated or implementing acts (such as regulatory technical standards) adopted by the European Commission and any regulations, requirements, guidelines, rules, standards and policies relating to minimum requirements for own funds and eligible liabilities adopted by the Federal Republic of Germany or the Republic of Italy, a relevant resolution authority or the European Banking Authority from time to time (whether or not such requirements, guidelines or policies are applied generally or specifically to the Issuer and/or the Group), as any of the preceding laws, regulations, requirements, guidelines, rules, standards, policies or interpretations may be amended, supplemented, superseded or replaced from time to time.