Expansion Effective on and as of December 1, 2017 (such date being the -Expansion Commencement Date”), the Premises shall be expanded to include an additional 7,389 square feet of rentable area designated as Suite 100 of the Building (the “Expansion Space”), being more fully shown and described on the floor plan attached hereto as Exhibit A and made a part hereof for all purposes, for a term that is coterminous with the Lease Term. Tenant acknowledges that the Expansion Space is currently occupied by an existing tenant (the “Existing Tenant”) and that Landlord and such Existing Tenant are concurrently herewith entering into an early termination agreement to terminate such Existing Tenant’s lease as of November 30, 2017. Tenant hereby waives any claims against Landlord in the event that such Existing Tenant holds over in the Premises beyond the Expansion Commencement Date. If such Existing Tenant holds over in the Expansion Space beyond the Expansion Commencement Date, the Expansion Commencement Date, and Xxxxxx’s obligation to commence paying rent with respect to the Expansion Space, shall nonetheless still commence on the Expansion Commencement Date. Following such Existing Tenant surrendering the Expansion Space to Landlord, Landlord shall thereafter deliver the same to Tenant. Upon the Expansion Commencement Date, Landlord may prepare and deliver to Tenant a certificate establishing the Expansion Commencement Date, which Tenant shall acknowledge by executing a copy and returning it to Landlord within ten (10) business days after its receipt from Landlord. Failure of Landlord to send any such certificate shall have no effect on the Expansion Commencement Date. In the event there is any delay in the delivery of the Expansion Space to Tenant (including, without limitation, due to the Existing Tenant holding over in the Expansion Space past the expiration of its lease), then this First Amendment shall not be void or voidable, nor shall Landlord be liable to Tenant for any loss or damage resulting therefrom. Xxxxxx has advised Landlord that it intends to permit Existing Tenant continue to occupy the Expansion Space through December 15, 2017, and Landlord hereby consents to Tenant permitting Existing Tenant to remain the Expansion Space through such date; provided, however, the Expansion Commencement Date, and Tenant’s obligation to commence paying rent with respect to the Expansion Space, shall commence on the Expansion Commencement Date.
Development Work Do, or cause to be done, such development and other work as may be reasonably necessary to protect from diminution and production capacity of the Mortgaged Property and each producing well thereon.
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
BUILDING PLANNING If Landlord requires the Premises for use by another ------------------ tenant or for other reasons connected with the Building planning program, then Landlord shall have the right, upon sixty (60) days' prior written notice to Tenant, to relocate the Premises to other space in the Building of substantially similar size as the Premises, and with tenant improvements of substantially similar age, quality and layout as then existing in the Premises. In the event of any such relocation, Landlord shall pay for the cost of providing substantially similar tenant improvements (but not any furniture or personal property), and Landlord shall reimburse Tenant, within thirty (30) days after Landlord's receipt of invoices and paid receipts, for the reasonable moving, telephone installation and stationery reprinting costs actually paid for by Tenant in connection with such relocation. If Landlord so relocates Tenant, the terms and conditions of this Lease shall remain in full force and effect and apply to the new space, except that (a) a revised Exhibit "B" shall become part ---------- of this Lease and shall reflect the location of the new space, (b) Paragraph 1 of this Lease shall be amended to include and state all correct data as to the new space, and (c) such new space shall thereafter be deemed to be the "Premises". Notwithstanding the foregoing provisions of this Paragraph 29 to the contrary, if the new space contains more Rentable Square Feet than the original Premises, Tenant shall not be obligated to pay any more Annual Basic Rent or Excess Expenses than otherwise applicable to the original Premises. Landlord and Tenant agree to cooperate fully in order to minimize the inconvenience of Tenant resulting from such relocation.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Project Plan Based on the Project Specifications, Omnicare CR has provided a description of services to be performed for Sponsor’s “A multi-center, randomized, double-blind, double-dummy, vehicle-controlled sequential cohort study to determine the safety of PEP005 0.025% and 0.05% topical gel in patients with actinic keratoses” (hereinafter “the Project”) and associated costs. Changes made in the Project scope, at any time during the Project, will result in a corresponding adjustment to the Project costs.
Commencement of Work Upon Contractor’s receipt from Owner of the limited notice to proceed (“Limited Notice to Proceed” or “LNTP”), Contractor shall promptly commence with the performance of the portion of the Work specified in such LNTP; provided that the Parties have executed a Change Order defining the LNTP Work. The LNTP shall be issued in the form attached hereto as Attachment H, Schedule H-1. Contractor shall not, and shall not be obligated to, commence performance of such Work until receipt from Owner of such LNTP.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.
Development of the Project The Board of Managers shall take such actions as shall be required to cause either the Company or the Management Company (as defined in Section 9(b) below) to perform and complete the construction and other development work as contemplated and/or required under the NVR Purchase and Sale Agreements, or any other construction company selected by the Board of Managers (the “Development Work”), substantially in accordance with the Project Plan, at a cost to the Company not exceeding the total cost set forth in the Budget, in a manner consistent with this Agreement and all applicable laws, ordinances, rules, regulations or requirements (including, without limitation, those with respect to discrimination) of governmental authorities, and in compliance with any covenants, conditions or restrictions affecting all or any portion of the Property.
