Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
CARE OF BUILDING AND EQUIPMENT Exhibitors or their agents shall not injure or deface any part of the exhibit building, the booths, or booth contents or show equipment and décor. When such damage appears, the exhibitor is liable to the owner of the property so damaged. 14.
Occupancy Restrictions For the purpose of satisfying the requirements of Section 42 of the Code, at least for the Qualified Project Period, the Owner hereby represents, covenants and agrees as follows:
PUBLIC WORKS AND BUILDING SERVICES CONTRACTS Work being done under a resulting Authorized User Agreement may be subject to the prevailing wage rate provisions of the New York State Labor Law. Such work will be identified by the Authorized User within the RFQ. See “Prevailing Wage Rates – Public Works and Building Services Contracts’ in Appendix B, Clause 10, OGS General Specifications. Any federal or State determination of a violation of any public works law or regulation, or labor law or regulation, or any OSHA violation deemed "serious or willful" may be grounds for a determination of vendor non-responsibility and rejection of proposal. The Prevailing Wage Case Number for this Contract is PRC# 2014011745. The Prevailing Wage Rates for various occupations and General Provisions of Laws Covering Workers on Article 8 Public Work Contract can be accessed at the following NYS Department of Labor website: xxxxx://xxxxxxxxxxxx.xxxxx.xx.xxx/wpp/xxxxXxxxXxxxxxx.xx?method=showIt Insert PRC# 2014011745 in the box provided and click Submit. Click Wage Schedule located underneath the main header of this page. The PDF file may be searched to obtain the Prevailing Wage Rate for a specific occupation. SHORT TERM EXTENSION In the event a replacement Contract has not been issued, any Contract let and awarded hereunder by the State, may be extended unilaterally by the State for an additional period of up to 3 months upon notice to the Contractor with the same terms and conditions as the original Contract including, but not limited to, prices and delivery requirements. With the concurrence of the Contractor, the extension may be for a period of up to 6 months in lieu of 3 months. However, this extension terminates should the replacement Contract be issued in the interim. PROCUREMENT INSTRUCTIONS Authorized Users should refer to the documents attached as Appendix G – Processes and Forms Templates for specific instructions on the usage of this Contract. OGS reserves the right to unilaterally make revisions, changes, additions and/or updates to the documents attached as Appendix G - Processes and Forms Templates without processing a formal amendment and/or modification. SPECIFICATIONS During the term of the Contract, the Authorized User may request Product specifications for particular items that have been included by the Contractor in its Pricing Pages. These specifications will be provided by the Contractor at no cost.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
Use of Buildings and Equipment 21.4.1 The Association shall have the right to use District buildings, sites, and equipment during all reasonable hours for meetings and other Association activities.
Certificate of Occupancy The Contractor’s obligation under the Contract is to install the Work in accordance with the Contract Documents, obtain the Certificate of Occupancy from the State Fire Marshal or his deputy, and forward it to the Design Professional as a part of the final close out procedures. The Design Professional’s obligation is to design the Work to comply with the applicable codes and to qualify for a Certificate of Occupancy.
Access to Project Site Redeveloper shall permit the representatives of the City to enter Project Site at any and all reasonable times, as the City may deem necessary for the purposes of this Redevelopment Agreement, including but not limited to work and inspection of all work being performed in connection with the construction of the Redeveloper Improvements. Similarly, the City shall permit Redeveloper such entry upon the public rights of way for such purposes. No compensation shall be payable nor shall any charges be made in any form by any party for the access or inspection provided for in this Section. The City’s right of access granted under this Section shall terminate upon issuance by the City of the Redeveloper’s Certificate of Completion of Redeveloper Improvements. Notwithstanding the above, Redeveloper shall not be relieved of the provisions contained in Chapter 14.29 of the Lincoln Municipal Code regarding the use of streets for private construction purposes.
Project Site The “Project Site” is the place where the Work is being carried on.
