Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Vendor License Requirements Vendor shall maintain, in current status, all federal, state, and local licenses, bonds and permits required for the operation of the business conducted by Vendor. Vendor shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of goods or services under the TIPS Agreement. TIPS and TIPS Members reserve the right to stop work and/or cancel a TIPS Sale or terminate this or any TIPS Sale Supplemental Agreement involving Vendor if Vendor’s license(s) required to perform under this Agreement or under the specific TIPS Sale have expired, lapsed, are suspended or terminated subject to a 30‐day cure period unless prohibited by applicable statue or regulation.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Information Systems Acquisition Development and Maintenance Security of System Files. To protect City Information Processing Systems and system files containing information, Service Provider will ensure that access to source code is restricted to authorized users whose specific job function necessitates such access.
Listing and Maintenance Requirements Compliance The Company has not in the two years preceding the date hereof received written notice from any stock exchange, market or trading facility on which the Common Stock is or has been listed or quoted to the effect that the Company is not in compliance with the listing, maintenance or other requirements of such exchange, market, trading or quotation facility. The Company has no reason to believe that it does not now or will not in the future meet any such requirements.
CONTRACT COMPLIANCE REQUIREMENT The HUB requirement on this Contract is 0%. The student engagement requirement of this Contract is 0 hours. The Career Education requirement for this Contract is 0 hours. Failure to achieve these requirements may result in the application of some or all of the sanctions set forth in Administrative Policy 3.10, which is hereby incorporated by reference.
License Requirements The Hotel’s alcoholic beverage license requires that the Hotel shall: (i) request proper identification (photo ID) of any person of questionable age and refuse alcoholic beverage service if the person is either under age or proper identification cannot be produced, and (ii) refuse alcoholic beverage service to any person who, in the Hotel’s judgment, appears to be intoxicated; and (iii) instruct its personnel to avoid encouraging patrons to consume alcoholic beverages (commonly referred to as “over-pouring”).
Design Development Phase INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
Development Phase contractual phase initiated with the approval of ANP for the Development Plan and which is extended during the Production Phase while investments in xxxxx, equipment, and facilities for the Production of Oil and Gas according to the Best Practices of the Oil Industry are required.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK Firms and/or individuals that assisted in the development or drafting of the specifications, requirements, statements of work, or solicitation documents contained herein are excluded from competing for this solicitation. This shall not be applicable to firms and/or individuals providing responses to a publicly posted Request for Information (RFI) associated with a solicitation.
