Payments Not Waiver or Acceptance of Work Sample Clauses

Payments Not Waiver or Acceptance of Work. No payment made by Owner under this Agreement shall constitute a waiver of any claim or right Owner may have at that time or thereafter, including claims regarding unsettled liens, warranty rights and indemnification obligations of GEC. No payment made by Owenr under this Agreement shall be considered or deemed to represent that Owner has inspected the Work or checked the quality or quantity of the Work or that Owner knows or has ascertained how or for what purpose GEC has used sums previously paid, and shall not be deemed or construed as an approval or acceptance of any Work or as a waiver of any claim or right Owner may have hereunder. Payments shall be subject to correction or adjustment in subsequent progress reviews and payments. Notwithstanding, to enable GEC to make timely and efficient corrections, Owner shall make any claims it has or could have raised within forty-five (45) Days of its becoming aware of the basis of such claim and no later than 45 days after Commercial Operation.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Payments Not Waiver or Acceptance of Work. No payment made by Owner under this Agreement shall constitute a waiver of any claim or right Owner may have at that time or thereafter, including claims regarding unsettled Liens, warranty rights and indemnification obligations of Contractor. Nor payment made by Owner under this Agreement shall be considered or deemed to represent that Owner has inspected the Work or checked the quality or quantity of the Work or that Owner knows or has ascertained how or for what purpose Contractor has used sums previously paid, and shall not be deemed or construed as an approval or acceptance of any Work or as a waiver of any claim or right Owner may have hereunder. All payments shall be subject to correction or adjustment in subsequent progress reviews and payments.
Sample 1
Payments Not Waiver or Acceptance of Work. No payment made by GEC under this Agreement shall constitute a waiver of any claim or right GEC may have at that time or thereafter, including claims regarding unsettled liens, warranty rights and indemnification obligations of Contractor. No payment made GEC/ICC/EPC 30 Confidential Business Information by GEC under this Agreement shall be considered or deemed to represent that GEC has inspected the Work or checked the quality or quantity of the Work or that GEC knows or has ascertained how or for what purpose Contractor has used sums previously paid, and shall not be deemed or construed as an approval or acceptance of any Work or as a waiver of any claim or right GEC may have hereunder. Payments shall be subject to correction or adjustment in subsequent progress reviews and payments. Notwithstanding, to enable Contractor to make timely and efficient corrections, GEC shall make any claims it has or could have raised within forty-five (45) Days of its becoming aware of the basis of such claim and no later than 45 days after Commercial Operation. GEC/ICC/EPC 31 Confidential Business Information
Sample 1
Payments Not Waiver or Acceptance of Work. No payment made by Owner under this Agreement shall constitute a waiver of any claim or right Owner may have at that time or thereafter.
Sample 1

Related to Payments Not Waiver or Acceptance of Work

  • Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.

  • Acceptance of Work Upon Purchaser’s written request and assurance that work has been com- pleted, Forest Service shall perform an inspection within 5 days, excluding weekends and Federal holidays, so as not to delay unnecessarily the progress of Purchaser’s Operations. Such a request may be for acceptance of:

  • Acceptance of the Terms of Use These terms of use are entered into by and between You and Insight Alliance (“Company,” “we,” or “us”). The following terms and conditions, together with any documents they expressly incorporate by reference (collectively, the “Terms of Use”), govern your access to and use of xxx.xxxxxxxxxxxxxxx.xxx, including any content, functionality, and services offered on or through xxx.xxxxxxxxxxxxxxx.xxx (the “Website”), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website, you accept and agree to be bound and abide by these Terms of Use and our Privacy Policy, incorporated herein by reference. If you do not want to agree to these Terms of Use or the Privacy Policy, you must not access or use the Website. This Website is offered and available to users who are 18 years of age or older and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet all of the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.

  • Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. The Architect, upon a finding of defect or failure to conform, shall immediately notify the State and Contractor, in writing, of the defect. The Contractor shall begin correcting the defective or non-conforming Work within ten (10) days unless the State agrees to a Change Order which reflects the reduction in Contract Sum due to the value of diminishment of the defective or nonconforming Work.

  • Acceptance of Agreement This Agreement shall not be considered accepted, approved or otherwise effective until the statutorily required approvals and certifications have been given.

  • Acceptance of Contract This contract shall not be considered accepted, approved or otherwise effective until the statutorily required approvals and certifications have been given.

  • NON-ACCEPTANCE OF SETTLEMENT AGREEMENT 33. If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.

  • Completion of Work Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order.

Time is Money Join Law Insider Premium to draft better contracts faster.