Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:
Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.
Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.
Notification of Claims In order that the indemnification provisions contained in this Section shall apply, upon the assertion of a claim for which either party may be required to indemnify the other, the party seeking indemnification shall promptly notify the other party of such assertion, and shall keep the other party advised with respect to all developments concerning such claim. The party who may be required to indemnify shall have the option to participate with the party seeking indemnification in the defense of such claim or to defend against said claim in its own name or in the name of the other party. The party seeking indemnification shall in no case confess any claim or make any compromise in any case in which the other party may be required to indemnify it except with the other party’s prior written consent.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Notice of Action The Borrower will promptly notify the Administrative Agent and the Lenders in writing of any threatened action, investigation or inquiry by any Governmental Authority of which the Borrower has knowledge in connection with any Environmental Laws, excluding action in respect of permit applications in the ordinary course of business and routine testing and corrective action.
Notification of Claim Notification of claim means the process of intimating a claim to the insurer or TPA through any of the recognized modes of communication.
Notice; Defense of Claims An indemnified party may make claims for indemnification hereunder by giving written notice thereof to the indemnifying party within the period in which indemnification claims can be made hereunder. If indemnification is sought for a claim or liability asserted by a third party, the indemnified party shall also give written notice thereof to the indemnifying party promptly after it receives notice of the claim or liability being asserted, but the failure to do so shall not relieve the indemnifying party from any liability except to the extent that it is prejudiced by the failure or delay in giving such notice. Such notice shall summarize the bases for the claim for indemnification and any claim or liability being asserted by a third party. Within 20 days after receiving such notice the indemnifying party shall give written notice to the indemnified party stating whether it disputes the claim for indemnification and whether it will defend against any third party claim or liability at its own cost and expense. If the indemnifying party fails to give notice that it disputes an indemnification claim within 20 days after receipt of notice thereof, it shall be deemed to have accepted and agreed to the claim, which shall become immediately due and payable. The indemnifying party shall be entitled to direct the defense against a third party claim or liability with counsel selected by it (subject to the consent of the indemnified party, which consent shall not be unreasonably withheld) as long as the indemnifying party is conducting a good faith and diligent defense. The indemnified party shall at all times have the right to fully participate in the defense of a third party claim or liability at its own expense directly or through counsel; provided, however, that if the named parties to the action or proceeding include both the indemnifying party and the indemnified party and the indemnified party is advised that representation of both parties by the same counsel would be inappropriate under applicable standards of professional conduct, the indemnified party may engage separate counsel at the expense of the indemnifying party. If no such notice of intent to dispute and defend a third party claim or liability is given by the indemnifying party, or if such good faith and diligent defense is not being or ceases to be conducted by the indemnifying party, the indemnified party shall have the right, at the expense of the indemnifying party, to undertake the defense of such claim or liability (with counsel selected by the indemnified party), and to compromise or settle it, exercising reasonable business judgment. If the third party claim or liability is one that by its nature cannot be defended solely by the indemnifying party, then the indemnified party shall make available such information and assistance as the indemnifying party may reasonably request and shall cooperate with the indemnifying party in such defense, at the expense of the indemnifying party.
Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:
Notice of Appeal In the event that an employee who has been laid off out of seniority order believes the decision based upon performance and/or qualifications is incorrect, the employee may request that the Association appeal the Sheriff’s determination. If the Association finds there is good reason to believe that the Sheriff has erred in his decision, it may appeal through the process set forth in this Article. Such appeal shall be filed within five (5) working days of delivery of the layoff notice to the employee.
