No Waiver of Immunities by Owner Sample Clauses

No Waiver of Immunities by Owner. Owner does not waive any of its immunities from lawsuit or damages, or both, as provided by the Texas law, as a public institution, whether granted by constitution, common law or statute; and nothing contained in the Architect Agreement, the Contract Documents and the Construction Documents, or any action required of the Owner by the Architect Agreement or the Contract Documents and the Construction Documents shall be interpreted to be such a waiver. EXECUTION PAGE NEITHER THIS AGREEMENT, NOR ANY PART THEREOF, NOR ANY DISPUTE ARISING UNDER THIS AGREEMENT, IS SUBJECT TO ARBITRATION.
Sample 1
AutoNDA by SimpleDocs
No Waiver of Immunities by Owner. Owner does not waive any of its immunities from lawsuit or damages, or both, as provided by the Texas law, as a public institution, whether granted by constitution, common law or statute; and nothing contained in the Architect Agreement, the Contract Documents, or any action required of the Owner by the Architect Agreement or the Contract Documents shall be interpreted to be such a waiver. NEITHER THIS AGREEMENT, NOR ANY PART THEREOF, NOR ANY DISPUTE ARISING UNDER THIS AGREEMENT, IS SUBJECT TO ARBITRATION. FOR ARCHITECT FOR OWNER By: By: Architect’s Representative Authorized Representative Dated: Dated: Approved as to Form: By: School Attorney (Remainder of page deliberately blank). (This section of page deliberately blank).
Sample 1

Related to No Waiver of Immunities by Owner

  • No Waiver of Immunities Nothing in this Agreement shall be deemed to waive, modify or amend any legal defense available at law or in equity to County, its past or present officers, employees, or agents or employees, nor to create any legal rights or claim on behalf of any third party. County does not waive, modify, or alter to any extent whatsoever the availability of the defense of governmental immunity under the laws of the Xxxxx xx Xxxxx xxx xx xxx Xxxxxx Xxxxxx.

  • No Waiver of Immunity Neither College nor School District waiver or relinquish any immunity or defense on behalf of itself, its trustees, officers, employees, and agents as a result of the execution of this MOU and the performance of the covenants contained herein.

  • NO WAIVER OF PROVISIONS The failure of the System Agency to object to or to take affirmative action with respect to any conduct of the Grantee which is in violation or breach of the terms of the Contract shall not be construed as a waiver of the violation or breach, or of any future violation or breach.

  • Waiver of Immunities To the extent that the Company or any of its properties, assets or revenues may have or may hereafter become entitled to, or have attributed to it, any right of immunity, on the grounds of sovereignty or otherwise, from any legal action, suit or proceeding, from the giving of any relief in any respect thereof, from setoff or counterclaim, from the jurisdiction of any court, from service of process, from attachment upon or prior to judgment, from attachment in aid of execution or judgment, or from execution of judgment, or other legal process or proceeding for the giving of any relief or for the enforcement of any judgment, in any jurisdiction in which proceedings may at any time be commenced, with respect to its obligations, liabilities or any other matter under or arising out of or in connection with the Shares or Deposited Securities, the American Depositary Shares, the Receipts or this Deposit Agreement, the Company, to the fullest extent permitted by law, hereby irrevocably and unconditionally waives, and agrees not to plead or claim, any immunity of that kind and consents to relief and enforcement as provided above.

  • No waiver of our rights (a) No failure on our part to exercise and no delay on our part in exercising any right or remedy under this agreement will operate as a waiver of such right or remedy, nor will any single or partial exercise of any right or remedy preclude any other or further exercise of such right or remedy or the exercise of any other right or remedy.

  • No Waiver of Sovereign Immunity Nothing in the Contract will be construed as a waiver of the System Agency’s or the State’s sovereign immunity. This Contract shall not constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas under the Contract or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. System Agency does not waive any privileges, rights, defenses, or immunities available to System Agency by entering into the Contract or by its conduct prior to or subsequent to entering into the Contract.

  • No Waiver of Rights A failure or delay in exercising any right, power or privilege in respect of this Agreement will not be presumed to operate as a waiver, and a single or partial exercise of any right, power or privilege will not be presumed to preclude any subsequent or further exercise, of that right, power or privilege or the exercise of any other right, power or privilege.

  • No Waiver of Sovereign Immunity or Powers Nothing in this agreement will be deemed to constitute a waiver of sovereign immunity or powers of licensee, the Xxxxxxxxxx County Commissioners Court, or the Xxxxxxxxxx County Judge.

  • NO WAIVER OF LEGAL RIGHTS The Employer and the Union agree that this program shall not diminish the rights of individual employees under State and/or Federal laws relating to drug and/or alcohol testing.

  • No Waiver of Fees Nothing in this Agreement, nor any entry or repossession of the Room by the Manager releases the Resident from any liability for the payment in full of all amounts payable under this Agreement for the Term.

Time is Money Join Law Insider Premium to draft better contracts faster.