Landlord’s Property All Alterations, improvements, fixtures, equipment and/or appurtenances which may be installed or placed in or about the Premises, from time to time, shall be at the sole cost of Tenant and shall be and become the property of Landlord; provided, however, Landlord may, by written notice to Tenant prior to the end of the Lease Term, or given following any earlier termination of this Lease, require Tenant, at Tenant’s expense, to remove any Alterations or improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to their condition existing prior to the installation of such Alterations or improvements or, at Landlord’s election, to a building standard tenant improved condition as determined by Landlord; provided; however, that notwithstanding the foregoing, upon request by Tenant at the time of Tenant’s request for Landlord’s consent to any Alteration or improvement, Landlord shall notify Tenant whether the applicable Alteration or improvement will be required to be removed pursuant to the terms of this Section 8.5. If Tenant fails to complete such removal and/or to repair any damage caused by the removal of any Alterations or improvements in the Premises and return the affected portion of the Premises to their condition existing prior to the installation of such Alterations or improvements or, if elected by Landlord, to a building standard tenant improved condition as determined by Landlord, prior to the expiration or earlier termination of this Lease, then Rent shall continue to accrue under this Lease in accordance with Article 16, below, after the end of the Lease Term until such work shall be completed, and Landlord shall have the right, but not the obligation, to perform such work and to charge the cost thereof to Tenant. Tenant hereby protects, defends, indemnifies and holds Landlord harmless from any liability, cost, obligation, expense or claim of lien, including but not limited to, court costs and reasonable attorneys’ fees, in any manner relating to the installation, placement, removal or financing of any such Alterations, improvements, fixtures and/or equipment in, on or about the Premises, which obligations of Tenant shall survive the expiration or earlier termination of this Lease.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.
Landlord’s Repair Obligations If this Lease does not terminate with respect to the entire Premises under Section 12.1, and if the Taking includes a portion of the Premises, then this Lease shall automatically terminate as to the portion of the Premises taken as of the date the Condemning Authority takes possession of the portion taken and Landlord will, at its sole cost and expense, restore the remaining portion of the Premises to a complete architectural unit with all commercially reasonable diligence and speed and will reduce the Basic Rent for the period after the date the Condemning Authority takes possession of the portion of the Premises taken to a sum equal to the product of the Basic Rent provided for in this Lease multiplied by a fraction, the numerator of which is the rentable area of the Premises after the Taking and after Landlord restores the Premises to a complete architectural unit, and the denominator of which is the rentable area of the Premises prior to the Taking. Landlord will also equitably adjust Tenant's Share of Expenses Percentage for the same period, subject to Section 3.7, to account for the reduction in the rentable area of the Premises or the Building resulting from the Taking. Tenant's obligation to pay Basic Rent and Tenant's Share of Expenses will xxxxx on a proportionate basis with respect to that portion of the Premises remaining after the Taking that Tenant is unable to use during Landlord's restoration for the period of time that Tenant is unable to use such portion of the Premises.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
LANDLORD'S LIABILITY If Landlord defaults under this Agreement and if, as a consequence of such default, Tenant shall recover a money judgment against Landlord, such judgment shall be satisfied against the right, title and interest of Landlord in the Shopping Center including, but not limited to, the rents, proceeds and profits derived therefrom as the same may then be constituted and encumbered, and Landlord shall not be liable for any deficiency. In no event shall Tenant have the right to levy execution against any property of Landlord other than its right, title and interest in the Shopping Center including, but not limited to, the rents, proceeds and profits derived therefrom. Upon any such uncured default by Landlord, Tenant may exercise any of its rights provided at law or in equity; provided, however: (a) Tenant shall have no right to offset or xxxxx rent in the event of any default by Landlord under this Agreement, except to the extent offset rights are specifically provided to Tenant in this Agreement; (b) Tenant shall have no right to terminate this Agreement unless determined by a court of competent jurisdiction under applicable law taking into account the nature of the breach; and (c) Tenant’s rights and remedies hereunder shall be limited to the extent this Agreement otherwise expressly limits Tenant’s rights or remedies. Notwithstanding anything contained in this Agreement to the contrary, the obligations of Landlord under this Agreement (including any actual or alleged breach or default by Landlord) do not constitute personal obligations of the individual partners, directors, officers, members or shareholders of Landlord or Landlord’s partners, and Tenant shall not seek recourse against the individual partners, directors, officers, members or shareholders of Landlord or against Landlord’s partners or any other persons or entities having any interest in Landlord, or any of their personal assets for satisfaction of any liability with respect to this Agreement. Notwithstanding anything contained in this Agreement to the contrary, in no event shall Landlord or any Landlord’s officers, trustees, directors, partners, beneficiaries, joint venturers, members, stockholders, or other principals or representatives, disclosed or undisclosed (and their respective successors and assigns) ever be liable pursuant to this Agreement for lost profits or consequential, speculative or punitive damages.
Landlord’s Entry Landlord and its authorized representatives may at all reasonable times and upon reasonable notice to Tenant enter the Premises to: (a) inspect the Premises; (b) exercise and perform Landlord's rights and obligations under this Lease; (c) post notices of non-responsibility or other protective notices available under the Laws; (d) show the Premises to current or prospective mortgagees, or to prospective purchasers of the Property; or (e) during the last 12 months of the Term, show the Premises to prospective tenants. Landlord, in the event of any emergency, may enter the Premises at any time without notice to Tenant. If Landlord receives prior written notification from Tenant that specified areas within the Premises contain confidential materials, then Landlord shall not enter such portions of the Premises unless accompanied by a representative of Tenant except (i) in case of an emergency, or (ii) if Tenant authorizes Landlord to enter such portions of the Premises without accompaniment of Tenant's representative. Landlord's entry into the Premises is not to be construed as a forcible or unlawful entry into, or detainer of, the Premises or as an eviction of Tenant from all or any part of the Premises. Subject to Section 9.3 below, Tenant will also permit Landlord (or its designees) to erect, install, use, maintain, replace and repair pipes, cables, conduits, plumbing and vents, and telephone, electric and other wires or other items, in, to and through the Premises if Landlord reasonably determines that such activities are necessary for properly operating and maintaining the Building.
