Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
WORK LETTER This Lease is supplemented by that certain Work Letter of even date executed by Lessor and Lessee, attached hereto as Exhibit C, and incorporated herein by this reference.
Landlord Improvements Landlord will construct a laboratory build-out for the Premises ("Landlord Improvements") pursuant to plans submitted by Landlord to Tenant and reasonably approved by Tenant ("Plans"), which shall be consistent with the floor plan attached hereto as Exhibit "C." The Plans generally shall provide for the Landlord Improvements to be constructed in order to accommodate generally accepted generic biotechnical laboratory uses, except as Landlord may otherwise agree. Unless otherwise determined by Landlord, the Tenant Improvements shall include the construction of an energy efficient electronically controlled central HV/AC plant. Within five (5) days after the Effective Date, Tenant shall provide to Landlord for Landlord's review and approval the following: (i) a proposed detailed list of equipment for the Premises, with the make, model, and specifications, and (ii) a detailed chemical inventory, with all codes and classifications. Tenant shall provide to Landlord such other information as Landlord may reasonably request for construction of the Landlord Improvements within five (5) days after written request therefor. Tenant shall provide written notice of its disapproval of the Plans within five (5) days after the Plans have been submitted detailing its precise reasons for disapproval. The failure of Tenant to disapprove the Plans in writing within a five (5) day period shall be conclusively deemed Tenant's approval of the Plans. Landlord shall have its architect revise the Plans to remedy any reasonable objections of Tenant, and Tenant shall have an additional five (5) day period to review the revised Plans to reasonably determine if such objections were satisfied; provided, however, Tenant shall make no new objections to the Plans. If there are any reasonable objections not addressed by revised Plans, the review procedure shall be repeated until all Tenant's objections are reasonably satisfied. If Tenant has not fully approved the Plans within sixty (60) days after the date such plans were first submitted to Tenant hereunder, Landlord at its sole election may terminate this Lease. Tenant shall timely sign and submit to Landlord a Certificate of Approval of Tenant Improvement Plans in the form as shown in Exhibit "F" attached to this Lease and incorporated herein by this reference ("Certificate"). In the case where Tenant is deemed to have approved the Plans on account of Tenant's failure to timely respond following the delivery of the Plans, such approval shall be deemed to have been given in accordance with the terms of the Certificate. Tenant acknowledges that Landlord may reasonably change the Plans as required by Applicable Law or unforeseen circumstances.
Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Landlord Services Any services provided by, or on behalf of, Landlord will not prevent any amounts received or accrued from qualifying as "Rents from real property" (within the meaning of Section 856(d)(2) or Section 512(b)(3) of the Code).
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Landlord Repairs Landlord, as an Expense, shall repair, replace when necessary (as reasonably determined by Landlord) and maintain in good repair the exterior of the Building (including exterior doors), parking, landscaping, exterior lighting, roof membrane, roof covering and all other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators, fire safety equipment, sewer and septic systems, the Emergency Generator and all other building systems serving the Premises and other portions of the Project (“Building Systems”), uninsured losses and damages caused by Tenant, or by any of Tenant’s Agents excluded. Landlord, at Landlord’s sole cost without right of reimbursement from Tenant, shall repair, replace when necessary (as reasonably determined by Landlord) and maintain the structural portions of the roof (specifically excluding the roof membrane and the roof covering, the repair and/or replacement of which shall be treated as an Expense), the foundation, footings, floor slab and load-bearing walls and exterior walls of the Building (excluding any glass and any routine maintenance, including, without limitation, any painting, sealing, patching and waterproofing of such walls, repair, the maintenance of which shall be treated as an Expense), uninsured losses and damages caused by Tenant or Tenant’s Agents excluded. Any losses and damages caused by Tenant or any Tenant Agent shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the reasonable judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, give Tenant not less than five (5) business days’ advance notice of any planned stoppage of Building Systems services for routine and planned maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this section, after which Landlord shall make a commercially reasonable effort to effect such repair within five (5) business days, or, where the repair cannot reasonably be completed within five (5) business days, as soon as reasonably possible thereafter. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after the time periods set forth herein. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Paragraph 21. Notwithstanding anything to the contrary contained in the Lease, commencing on the Assumption Date, to the extent that Landlord performs or is required to perform any capital repairs, replacements or improvements for the Project, whether to comply with Law, with any obligation imposed on Landlord pursuant to this Lease or at Landlord’s election, Tenant shall be responsible as part of Expenses for its Proportionate Share of the cost of such capital repairs, replacements and improvements amortized over the useful life (as reasonably determined by Landlord taking into account relevant real estate accounting principles, consistently applied, including, without limitation, the hours of operation of the Building and its use for laboratory/office purposes) of such capital items. Tenant shall pay Tenant’s Proportionate Share of such amortized costs for each month after such capital repairs, replacements or improvements are completed until the first to occur of the expiration of the Term (as it may be extended) or the end of the period over which such costs are amortized.
Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
