Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Approval Procedure 1. To request approval to receive shared leave hours, an employee or their representative must submit the following documentation to Human Resource Services:
ROAD WORK PHASE APPROVAL Purchaser shall obtain written approval from the Contract Administrator upon completion of each of the following phases of road work: Drainage installation Subgrade compaction Rock compaction SUBSECTION RESTRICTIONS
REGULATORY FILINGS AND CAISO TARIFF COMPLIANCE 3.1 Filing
Updated Information Submission by Interconnection Customer The updated information submission by the Interconnection Customer, including manufacturer information, shall occur no later than one hundred eighty (180) Calendar Days prior to the Trial Operation. The Interconnection Customer shall submit a completed copy of the Electric Generating Unit data requirements contained in Appendix 1 to the LGIP. It shall also include any additional information provided to the Participating TO and the CAISO for the Interconnection Studies. Information in this submission shall be the most current Electric Generating Unit design or expected performance data. Information submitted for stability models shall be compatible with the Participating TO and CAISO standard models. If there is no compatible model, the Interconnection Customer will work with a consultant mutually agreed to by the Parties to develop and supply a standard model and associated information. If the Interconnection Customer's data is materially different from what was originally provided to the Participating TO and the CAISO for the Interconnection Studies, then the Participating TO and the CAISO will conduct appropriate studies pursuant to the LGIP to determine the impact on the Participating TO’s Transmission System and affected portions of the CAISO Controlled Grid based on the actual data submitted pursuant to this Article 24.3. The Interconnection Customer shall not begin Trial Operation until such studies are completed and all other requirements of this LGIA are satisfied.
NYS OFFICE OF INFORMATION TECHNOLOGY SERVICES NOTIFICATION All New York State Agencies must notify the Office of Information Technology Services of any and all plans to procure IT and IT -related products, materials and services meeting required thresholds defined in Technology Policy NYS–P08-001: xxxxx://xxx.xx.xxx/sites/default/files/documents/NYS-P08-001.pdf, as may be amended, modified or superseded. SALES REPORTING REQUIREMENTS Contractor shall furnish OGS with quarterly sales reports utilizing Appendix I - Report of Contract Sales. Purchases by Non- State Agencies, political subdivisions and others authorized by law shall be reported in the same report and indicated as required. All fields of information shall be accurate and complete. OGS reserves the right to unilaterally make revisions, changes and/or updates to Appendix I - Report of Contract Sales or to require sales to be reported in a different format without processing a formal amendment and/or modification. Further, additional related sales information and/or detailed Authorized User purchases may be required by OGS and must be supplied upon request. Reseller Sales Product sold through Reseller(s) must be reported by Contractor in the required Appendix I – Report of Contract Sales. Due Date The Appendix I - Report of Contract Sales will be quarterly (January - March, April - June, July - September and October - December). Reports will be due 1 month after the closing quarter. SERVICE REPORTS FOR MAINTENANCE/SUPPORT AND WARRANTY WORK Service Reports for Authorized User An Authorized User in an RFQ may require compliance with any or all of this section. If requested by the Authorized User, the Contractor shall furnish the Authorized User with service reports for all Maintenance/support and warranty work upon completion of the services. The service reports may include the following information in either electronic or hard copy form as designated by the Authorized User: Date and time Contractor was notified Date and time of Contractor’s arrival Make and model of the Product Description of malfunction reported by Authorized User Diagnosis of failure and/or work performed by Contractor Date and time failure was corrected by Contractor Type of service – Maintenance/support or warranty Charges, if any, for the service Service Reports for OGS
Application and Submission Information In addition to the application and submission language discussed in PART II: Section I, you must include the following in your application:
Search, Enquiry, Investigation, Examination And Verification a. The Property is sold on an “as is where is basis” subject to all the necessary inspection, search (including but not limited to the status of title), enquiry (including but not limited to the terms of consent to transfer and/or assignment and outstanding charges), investigation, examination and verification of which the Purchaser is already advised to conduct prior to the auction and which the Purchaser warrants to the Assignee has been conducted by the Purchaser’s independent legal advisors at the time of execution of the Memorandum.
NOTIFICATIONS AND SUBMISSION OF REPORTS Unless otherwise stated in writing after the Effective Date, all notifications and reports required under this IA shall be submitted to the following entities: OIG: Administrative and Civil Remedies Branch Office of Counsel to the Inspector General Office of Inspector General U.S. Department of Health and Human Services Xxxxx Building, Room 5527 000 Xxxxxxxxxxxx Xxxxxx, XX Xxxxxxxxxx, XX 00000 Telephone: (000) 000-0000 Facsimile: (000) 000-0000 LFAC: Xxxxxxx X. Xxxxx, DPM 0000 Xxxxxxxxxxx Xx. X-000 Xxxxxxxxx, XX 00000 Telephone: (000) 000-0000 Email: xx.xxxxx@xxxxx.xxx Unless otherwise specified, all notifications and reports required by this IA may be made by electronic mail, overnight mail, hand delivery, or other means, provided that there is proof that such notification was received. Upon request by OIG, LFAC may be required to provide OIG with an additional copy of each notification or report required by this IA in OIG’s requested format (electronic or paper).
Reports and Government access The Contractor shall promptly furnish reports, certificates, financial statements, and other pertinent information requested by the Contracting Officer for the administration of this clause and to determine that an event or other criterion prompting a financing payment has been successfully accomplished. The Contractor shall give the Government reasonable opportunity to examine and verify the Contractor's records and to examine and verify the Contractor's performance of this contract for administration of this clause.
