ECR Number Environmental Commitment Record Requirements Description of ADOT Responsibilities TMP-3 The following measures will be implemented for the Selected Alternative: • All equipment exhaust systems will be in good working order. Properly designed engine enclosures and intake silencers will be used. • Equipment will be maintained on a regular basis. New equipment will be subject to new product emission standards. • Stationary equipment will be located as far away from sensitive receivers as possible. • Construction-related noise generators will be shielded from noise receivers (e.g., use temporary enclosures to shield generators or crushers, take advantage of site conditions to provide topographic separation). • Construction alerts will be distributed to keep the public informed of construction activities, and a toll-free number for construction-related complaints will be provided. • During the design phase, hours of operation will be evaluated to minimize disruptions during construction. ADOT to oversee for compliance TMP-4 Congestion from construction-related traffic will create temporary impacts in the project vicinity. The magnitude of these impacts will vary depending on the location of the sources of the fill material and of the disposition sites for surplus material, the land uses along the routes, the duration of hauling operations, staging locations, and the construction phasing. To identify acceptable routes and times of operation, ADOT, or its representative, will prepare an agreement with local agencies regarding hauling of construction materials on public streets. ADOT to oversee for compliance TP Attachment 000-0 Xxxxx Xxxxxxxx Xxxxxxx Project Record of Decision (ROD) Developer’s Environmental Commitment Requirements The following table includes the Project-specific environmental commitments as written in the ROD, with minor modifications for clarification purposes. As it relates to these Technical Provisions, references to freeway, project, South Mountain Freeway, proposed action, proposed freeway, and Selected Alternative mean the Project, and references to contractor mean Developer. Developer shall comply with and perform all of the contractor and ADOT requirements, including the ADOT obligations, commitments, and responsibilities, identified in the following table, except to the extent of those requirements that are specifically identified in the third column, entitled “Description of ADOT Responsibilities,” which are not delegated to Developer.
Additional Procedures Applicable to High Value Accounts 1. If a Preexisting Individual Account is a High Value Account as of December 31, 2013, the Reporting [FATCA Partner] Financial Institution must complete the enhanced review procedures described in paragraph D of this section with respect to such account by December 31, 2014. If based on this review, such account is identified as a U.S. Reportable Account, the Reporting [FATCA Partner] Financial Institution must report the required information about such account with respect to 2013 and 2014 in the first report on the Account. For all subsequent years, information about the account should be reported on an annual basis.
Definition of Building Where Lift Required 1.1 A passenger/materials lift shall be provided on a building which shall, when complete, consist of more than six (6) storey levels excluding the roof, parapets and basement levels (if any), but including the ground floor. (Refer to Sub Clause 2.1 herein.)
Exclusion of applications on preliminary points of law Any recourse to any Court for the determination of a preliminary point of law arising in the course of the arbitration proceedings is excluded.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Retention or Repurchase of Assets Essential to Receiver (a) The Receiver may refuse to sell to the Assuming Institution, or the Assuming Institution agrees, at the request of the Receiver set forth in a written notice to the Assuming Institution, to assign, transfer, convey, and deliver to the Receiver all of the Assuming Institution's right, title and interest in and to, any Asset or asset essential to the Receiver as determined by the Receiver in its discretion (together with all Credit Documents evidencing or pertaining thereto), which may include any Asset or asset that the Receiver determines to be:
Certain Requirements as to Furniture, Equipment and Fixtures If the Assuming Institution purchases owned Bank Premises or accepts an assignment of the lease (or enters into a sublease or a new lease in lieu thereof) for leased Bank Premises as provided in Section 4.6(a) or 4.6(b), or if the Assuming Institution does not exercise such option but within twelve (12) months following Bank Closing obtains the right to occupy such premises (whether by assignment, lease, sublease, purchase or otherwise), other than in accordance with Section 4.6(a) or (b), the Assuming Institution shall (i) effective as of the date of Bank Closing, purchase from the Receiver all Furniture and Equipment and Fixtures owned by the Failed Bank at Fair Market Value and located thereon as of Bank Closing, (ii) accept an assignment or a sublease of the leases or negotiate new leases for all Furniture and Equipment and Fixtures leased by the Failed Bank and located thereon, and (iii) if applicable, accept an assignment or a sublease of any ground lease or negotiate a new ground lease with respect to any land on which such Bank Premises are located; provided, that the Receiver shall not have disposed of such Furniture and Equipment and Fixtures or repudiated the leases specified in clause (ii) or (iii).
COMPLIANCE WITH LICENSING REQUIREMENTS CONTRACTOR shall comply with all necessary licensing requirements and shall obtain appropriate licenses and display the same in a location that is reasonably conspicuous, as well as file copies of same with the County Executive Office.
