Exception to Obligations Neither Party's obligations under this Section shall apply to the extent the infringement is caused by: (i) modification of the facilities or equipment (including software) by the indemnitee; (ii) use by the indemnitee of the facilities or equipment (including software) in combination with equipment or facilities (including software) not provided or authorized by the indemnitor, provided the facilities or equipment (including software) would not be infringing if used alone; (iii) conformance to specifications of the indemnitee which would necessarily result in infringement; or (iv) continued use by the indemnitee of the affected facilities or equipment (including software) after being placed on notice to discontinue use as set forth herein.
Card Replacement Fee If your account is subject to a Card Replacement Fee, a fee will be charged for each replacement card that is issued to you for any reason.
Service Fees and Additional Charges Any applicable fees will be charged regardless of whether the Service was used during the billing cycle. There may be a charge for additional transactions and other optional services. You agree to pay such charges and authorize the Service to deduct the calculated amount from your designated Billing Account for these amounts and any additional charges that may be incurred by you. Any financial fees associated with your standard deposit accounts will continue to apply. You are responsible for any and all telephone access fees and/or Internet service fees that may be assessed by your telephone and/or Internet service provider.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
CERTIFICATION OF NONSEGREGATED FACILITIES (Applicable to construction contracts exceeding $10,000) The Contractor certifies that it does not maintain or provide for its establishments, and that it does not permit employees to perform their services at any location, under its control, where segregated facilities are maintained. It certifies further that it will not maintain or provide for employees any segregated facilities at any of its establishments, and it will not permit employees to perform their services at any location under its control where segregated facilities are maintained. The Contractor agrees that a breach of this certification is a violation of the equal opportunity clause of this contract. As used in this certification, the term “segregated facilities” means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms, and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation and housing facilities provided for employees which are segregated by explicit directive or are, in fact, segregated on the basis of race, color, religion, or national origin because of habit, local custom, or any other reason. The Contractor further agrees that (except where it has obtained for specific time periods) it will obtain identical certification from proposed subcontractors prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the equal opportunity clause; that it will retain such certifications in its files; and that it will forward the preceding notice to such proposed subcontractors (except where proposed subcontractors have submitted identical certifications for specific time periods).
Maintenance, Repair and Replacement Subject to the provisions of Article 10.00 and payment by the Tenant of Rent, the Landlord shall operate, maintain, repair and replace the systems, facilities and equipment necessary for the proper operation of the Project and for provision of the Landlord's Services set out in Section 6.02 (except as may be installed by or be the property of the Tenant) and shall maintain and repair the foundations, structure and roof of the Building and repair damage to the Building which the Landlord is obligated to insure against under Article 9.00, provided that:
RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost prepared by the Design Professional represent the Design Professional's best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Design Professional nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding or market conditions. Accordingly, the Design Professional cannot and does not warrant or represent that bids or cost proposals will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Design Professional.
FILOT Payments on Replacement Property If the Company or any Sponsor Affiliate elects to replace any Removed Components and to substitute such Removed Components with Replacement Property as a part of the Economic Development Property, or the Company or any Sponsor Affiliate otherwise utilizes Replacement Property, then, pursuant and subject to the provisions of Section 12-44-60 of the FILOT Act, the Company or such Sponsor Affiliate shall make statutory payments in lieu of ad valorem taxes with regard to such Replacement Property in accordance with the following:
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Taxes and Fees Imposed on Providing Party But Passed On To Purchasing Party 11.4.1 Taxes and fees imposed on the providing Party, which are permitted or required to be passed on by the providing Party to its customer, shall be borne by the purchasing Party.
