Delay in Delivery of Leased Premises Sample Clauses

Delay in Delivery of Leased Premises. If due to reasons attributable to the Landlord or to Unavoidable Delay due to reasons attributable to the Tenant (including any even of Unavoidable Delay attributable to the Tenant), the Leased Premises are not substantially completed as provided in Section 4.2 of the Lease by the Delivery Date and as a result possession of the Leased Premises is given to the Tenant later than the Delivery Date, the Commencement Date of the Lease and termination date, and all other dates and delays stipulated herein will be moved forward by the same number of days as the delay in giving possession. The Tenant shall not be entitled to any damages or indemnity whatsoever resulting from such delay and agrees to accept any such extension as full and final settlement of any and all claims which the Tenant may otherwise have by reason of any delay in delivering possession of the Lease Premises. Any delay in delivering possession of the Leased Premises due to reasons attributable to the Tenant (including any event of Unavoidable Delay attributable to the Tenant), shall not entail extension of the Commencement Date or termination date of the Lease nor entitle the Tenant to any compensation whatsoever.
Sample 1
AutoNDA by SimpleDocs

Related to Delay in Delivery of Leased Premises

  • Acceptance of Leased Premises Tenant acknowledges that: (a) it has been advised by Landlord, Landlord’s Broker and Tenant’s Broker, if any, to satisfy itself with respect to the condition of the Leased Premises (including, without limitation, the HVAC, electrical, plumbing and other mechanical installations, fire sprinkler systems, security, environmental aspects, and compliance with applicable laws, ordinances, rules and regulations) and the present and future suitability of the Leased Premises for Tenant’s intended use; (b) Tenant has made such inspection and investigation as it deems necessary with reference to such matters and assumes all responsibility therefor as the same relate to Xxxxxx’s occupancy of the Leased Premises and the Term of this Lease; and (c) neither Landlord nor Landlord’s Broker nor any of Landlord’s agents has made any oral or written representations or warranties with respect to the condition, suitability or fitness of the Leased Premises other than as may be specifically set forth in this Lease. Tenant accepts the Leased Premises in its AS IS condition existing on the date Tenant executes this Lease, subject to all matters of record and applicable laws, ordinances, rules and regulations. Tenant acknowledges that neither Landlord nor Landlord’s Broker nor any of Landlord’s agents has agreed to undertake any alterations or additions or to perform any maintenance or repair of the Leased Premises except for the routine maintenance and janitorial work specified herein and except as may be expressly set forth in Exhibit B. If Landlord, for any reason whatsoever, cannot deliver possession of the Leased Premises to Tenant on the estimated commencement date in the condition specified in this Section 2.2, Landlord shall neither be subject to any liability nor shall the validity of this Lease be affected; provided, the Term and the obligation to pay Gross Rent shall commence on the date possession is actually tendered to Tenant (which date shall become the Term Commencement Date) and the Term Expiration Date shall be extended commensurately. If the Term Commencement Date and/or the Term Expiration Date is other than the Term Commencement Date and Term Expiration Date specified in the Basic Lease Information or is not set forth in the Basic Lease Information, the parties shall execute that certain Confirmation of Term of Lease, substantially in the form of Exhibit C hereto specifying the actual Term Commencement Date, Term Expiration Date and the date on which Tenant is to commence paying Rent. Tenant shall execute and return such Confirmation of Term of Lease to Landlord within fifteen (15) days after Xxxxxx’s receipt thereof. If Xxxxxx fails to execute and return (or reasonably object in writing to) the Confirmation of Term of Lease within fifteen (15) days after receiving it, Tenant shall be deemed to have executed and returned it without exception.

  • Condition of Leased Premises Tenant hereby acknowledges that Xxxxxx has examined the leased premises prior to the signing of this Lease, or knowingly waived said examination. Tenant acknowledges that Tenant has not relied on any representations made by Landlord or Landlord’s agents regarding the condition of the leased premises and that Tenant takes premises in its AS-IS condition with no express or implied warranties or representations beyond those contained herein or required by applicable Georgia law. Xxxxxx agrees not to damage the premises through any act or omission, and to be responsible for any damages sustained through the acts or omissions of Tenant, Xxxxxx’s family or Xxxxxx’s invitees, licensees, and/or guests. If such damages are incurred, Tenant is required to pay for any resulting repairs at the same time and in addition to the next month’s rent payment, with consequences for non-payment identical to those for non- payment of rent described herein. At the expiration or termination of the Lease, Tenant shall return the leased premises in as good condition as when taken by Tenant at the commencement of the lease, with only normal wear-and-tear excepted. Modification Of This Lease Any modification of this lease shall not be binding upon Landlord unless in writing and signed by Landlord or Landlord’s authorized agent. No oral representation shall be effective to modify this Lease. If, as per the terms of this paragraph, any provision of this lease is newly added, modified, or stricken out, the remainder of this Lease shall remain in full force and effect.

  • Destruction of Leased Premises In the event the Premises shall be partially or totally destroyed as the result of a peril insured against by the insurance policies carried by Landlord and such damage renders the Premises partially or totally untenantable, Landlord shall repair the Premises to the lesser of (i) with respect to the Premises, the condition of the Premises inclusive of Landlord improvements, but exclusive of Tenant improvements, as of lease commencement adjusted for ordinary wear and tear; or (ii) the extent of the insurance proceeds actually received by Landlord allocable to the Premises plus insurance proceeds received by Tenant for the risks set forth herein, which Tenant shall promptly pay over to Landlord to the extent of the costs incurred by Landlord in such repairs and reconstruction in excess of the insurance proceeds, if any, received directly by Landlord. Tenant's insurance carriers shall have not recourse against the Landlord for reimbursement. The Fixed Minimum Rental and other charges shall be abated in proportion to the amount of the Leased Premises rendered untenantable until so repaired. If: (i) more than Twenty percent (20%) of the floor area of the building in which the Leased Premises are located shall be damaged or destroyed by fire or other insured casualty; or (ii) if there is less than Three (3) years of the term of this Lease remaining; (iii) or if in Landlord's opinion the Premises is so extensively or substantially damaged so that reconstruction is impracticable; then Landlord may either elect that the Premises may be repaired or rebuilt or, at its sole option, terminate this Lease by giving Notice to Tenant of its election to so terminate, such Notice to be given within Ninety (90) days after the occurrence of such damage or destruction, and Tenant's obligations to pay rent shall cease as of such date. If Landlord is required or elects to repair or rebuild the Leased Premises as herein provided, Tenant shall repair or replace its merchandise, trade fixtures, furnishings, and equipment in a manner and to at least a condition equal to that prior to its damage or destruction. Tenant shall diligently undertake such repair or replacement in cooperation with Landlord and shall complete such replacement or repair no later than Thirty (30) days after Landlord notifies Tenant that the Premises are ready for occupancy and all rent and other charges shall resume in full as of such date. Landlord and Tenant shall agree upon an equitable reduction in Rent in the event this Lease is not terminated and the Premises or the Leased Premises are damaged or destroyed to such an extent that it materially and adversely affects Tenant's business. Such abatement shall in no event exceed the proportion of the square footage of the Premises which is not tenantable.

  • DEMISE OF LEASED PREMISES Landlord hereby leases to Tenant and Tenant hereby leases from Landlord for Tenant's own use in the conduct of Tenant's business and not for purposes of speculating in real estate, for the Lease Term and upon the terms and subject to the conditions of this Lease, that certain interior space described in Article 1 as the Leased Premises, reserving and excepting to Landlord the right to fifty percent (50%) of all assignment consideration and excess rentals as provided in Article 7 below. Tenant's lease of the Leased Premises, together with the appurtenant right to use the Outside Areas as described in Paragraph 2.2 below, shall be conditioned upon and be subject to the continuing compliance by Tenant with (i) all the terms and conditions of this Lease, (ii) all Laws governing the use of the Leased Premises and the Property, (iii) all Private Restrictions, easements and other matters now of public record respecting the use of the Leased Premises and Property, and (iv) all reasonable rules and regulations from time to time established by Landlord. Notwithstanding any provision of this Lease to the contrary, Landlord hereby reserves to itself and its designees all rights of access, use and occupancy of the Building roof, and Tenant shall have no right of access, use or occupancy of the Building roof except (if at all) to the extent required in order to enable Tenant to perform Tenant's maintenance and repair obligations pursuant to this Lease.

  • Use of Leased Premises The Leased Premises are to be used by Tenant solely for the Permitted Use and for no other purposes without the prior written consent of Landlord.

  • Condition of Leased Property Tenant acknowledges receipt and delivery of possession of the Leased Property and Tenant accepts the Leased Property in its “as is” condition, subject to the rights of parties in possession, the existing state of title, including all covenants, conditions, restrictions, reservations, mineral leases, easements and other matters of record or that are visible or apparent on the Leased Property, all applicable Legal Requirements, the lien of any financing instruments, mortgages and deeds of trust existing prior to the Commencement Date or permitted by the terms of this Agreement, and such other matters which would be disclosed by an inspection of the Leased Property and the record title thereto or by an accurate survey thereof. TENANT REPRESENTS THAT IT HAS INSPECTED THE LEASED PROPERTY AND ALL OF THE FOREGOING AND HAS FOUND THE CONDITION THEREOF SATISFACTORY AND IS NOT RELYING ON ANY REPRESENTATION OR WARRANTY OF LANDLORD OR LANDLORD’S AGENTS OR EMPLOYEES WITH RESPECT THERETO AND TENANT WAIVES ANY CLAIM OR ACTION AGAINST LANDLORD IN RESPECT OF THE CONDITION OF THE LEASED PROPERTY. LANDLORD MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY TENANT. To the maximum extent permitted by law, however, Landlord hereby assigns to Tenant all of Landlord’s rights to proceed against any predecessor in interest or insurer for breaches of warranties or representations or for latent defects in the Leased Property. Landlord shall fully cooperate with Tenant in the prosecution of any such claims, in Landlord’s or Tenant’s name, all at Tenant’s sole cost and expense. Tenant shall indemnify, defend, and hold harmless Landlord from and against any loss, cost, damage or liability (including reasonable attorneys’ fees) incurred by Landlord in connection with such cooperation.

  • Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.

  • Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.

  • Sublease Premises On and subject to the terms and conditions below, Sublandlord hereby leases to Subtenant, and Subtenant hereby leases from Sublandlord, the Sublease Premises.

  • Subleased Premises Sublandlord does hereby sublease to Subtenant, and Subtenant subleases and rents from Sublandlord, the Premises (the “Subleased Premises”).

Time is Money Join Law Insider Premium to draft better contracts faster.