City’s Right to Terminate for Convenience City may, at its sole option and for its convenience, terminate all or any portion of this Contract by giving thirty (30) days’ written notice of such termination to Contractor. The termination of the Contract shall be effective upon receipt of the notice by Contractor. After termination of all or any portion of the Contract, Contractor shall: (1) immediately discontinue all affected performance (unless the notice directs otherwise); and (2) complete any and all additional work necessary for the orderly filing of documents and closing of Contractor's affected performance under the Contract. After filing of documents and completion of performance, Contractor shall deliver to City all data, drawings, specifications, reports, estimates, summaries, and such other information and materials created or received by Contractor in performing this Contract, whether completed or in process. By accepting payment for completion, filing, and delivering documents as called for in this section, Contractor discharges City of all of City’s payment obligations and liabilities under this Contract with regard to the affected performance.
RIGHT TO AMEND This Agreement may only be amended through written consent of the Parties.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
City’s Right to Reject The City reserves the right to reject a certificate of insurance if Contractor’s insurance company is widely regarded in the insurance industry as financially unstable. This would include but is not limited to insurance companies with no less than AVIII rating in the A.M. Best insurance rating guide.
HELP FOR PERSONS AFFECTED BY ALCOHOL AND/OR OTHER DRUGS The OH&S Committee and management will provide information and assistance to persons seeking help for alcohol/drug problems or related problems, confidentially and without prejudice. • Sick leave or leave without pay may be negotiated to enable participation in rehabilitation or counselling. • No-one will be disadvantaged in the workplace as a result of undertaking a rehabilitation program.
Modifications to Service This Auction Site reserves the right to modify or discontinue the Service with or without notice to user. This Auction Site shall not be liable to users or any third party should this Auction Site exercise its right to modify or discontinue the Service.
CFR PART 200 Domestic Preferences for Procurements As appropriate and to the extent consistent with law, the non-Federal entity should, to the greatest extent practicable under a Federal award, provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). The requirements of this section must be included in all subawards including all contracts and purchase orders for work or products under this award. For purposes of 2 CFR Part 200.322, “Produced in the United States” means, for iron and steel products, that all manufacturing processes, from the initial melting stag through the application of coatings, occurred in the United States. Moreover, for purposes of 2 CFR Part 200.322, “Manufactured products” means items and construction materials composed in whole or in part of non-ferrous metals such as aluminum, plastics and polymer-based products such as polyvinyl chloride pipe, aggregates such as concrete, class, including optical fiber, and lumber. Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, Vendor certifies that to the greatest extent practicable Vendor will provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). Does vendor agree? Yes
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.1.5. There is no legal limitation on the Owner’s right to make changes such as may be, in the Owner’s sole discretion, useful or desirable to the Project.
Waiver of Right to Appeal Provided the Judgment is consistent with the terms and conditions of this Agreement, specifically including the Class Counsel Fees Payment and Class Counsel Litigation Expenses Payment reflected set forth in this Settlement, the Parties, their respective counsel, and all Participating Class Members who did not object to the Settlement as provided in this Agreement, waive all rights to appeal from the Judgment, including all rights to post-judgment and appellate proceedings, the right to file motions to vacate judgment, motions for new trial, extraordinary writs, and appeals. The waiver of appeal does not include any waiver of the right to oppose such motions, writs or appeals. If an objector appeals the Judgment, the Parties’ obligations to perform under this Agreement will be suspended until such time as the appeal is finally resolved and the Judgment becomes final, except as to matters that do not affect the amount of the Net Settlement Amount.
Notice of Right to Cancel YOU MAY CANCEL THIS CONTRACT AT ANY TIME PRIOR TO MIDNIGHT OF THE THIRD BUSINESS DAY AFTER THE DATE YOU SIGN THIS CONTRACT. SEE EXHIBIT 1, THE ATTACHED NOTICE OF CANCELLATION FORM FOR AN EXPLANATION OF THIS RIGHT.
