Cost Overruns The Borrower shall ensure that all cost-overruns over the estimated construction costs of the Project as certified by a quantity surveyor or the Architect or as ascertained by the Lender as and when they occur shall be funded by the Borrower’s own equity;
Direct Costs Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.
Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Development Costs With respect to activities prior to the Amendment Effective Date, each Party was to pay [*] of the total Direct Development Costs of a Product incurred in accordance with the Development Budget (as defined in the Original Agreement). Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, with respect to activities on and after the Amendment Effective Date, subject to Sections 3.1.2, Alimera will be solely responsible for, and shall pay one hundred percent (100%) of, all development costs of a Product, including Direct Development Costs. Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, (i) all payments owing by CDS hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by CDS (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), further including any penalties and interest which might have accrued with respect thereto, and further including all CDS payments deferred pursuant to that February 11, 2008 letter agreement sent by CDS and executed by CDS and Alimera regarding deferral of payments under the Original Agreement as of such date; (ii) all payments owing by Alimera hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by Alimera (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), and further including any penalties and interest which might have accrued with respect thereto; and (iii) subject to Sections 3.1.1 and 3.1.2, from and after the Amendment Effective Date, CDS will have no liability whatsoever hereunder for any past, present or future development costs, including Direct Development Costs (which includes those incurred before, on and after the Amendment Effective Date), and instead Alimera shall have sole liability therefor.
Excess Costs If the Permitted Costs exceeds the Finish Allowance, then Tenant shall pay all such excess costs (“Excess Costs”), provided, however, Landlord will, prior to the commencement of construction of Tenant’s Improvements, advise Tenant of the sum of the Contract Sum and the Construction Management Fee (the “Cost Estimate”). Tenant shall have five (5) business days from and after the receipt of such advice within which to approve or disapprove the Contract Sum and Cost Estimate. If Tenant fails to approve same by the expiration of the fifth such business day, then Tenant shall be deemed to have approved the Proposed Contract Sum and Cost Estimate. If Tenant disapproves the Contract Sum and Cost Estimate within such five (5) business day period, then Tenant shall either reduce the scope of Tenant’s Improvements such that the Contract Sum and Construction Management Fee do not exceed the Finish Allowance or, at Tenant’s option, Landlord shall obtain two (2) additional bids, provided that each day beyond such five (5) business day period and until the rebid is accepted by Tenant shall constitute a Tenant Delay hereunder. The foregoing process shall continue until a Contract Sum and Cost Estimate are accepted or deemed accepted by Tenant. Landlord and Tenant must approve (or be deemed to have approved) the Contract Sum for the construction of Tenant’s Improvements in writing prior to the commencement of construction.
Attorneys’ Fees and Cost of Collection In the event of any arbitration or action at law or in equity to enforce or interpret the terms of this Agreement or any of the other Transaction Documents, the parties agree that the party who is awarded the most money (which, for the avoidance of doubt, shall be determined without regard to any statutory fines, penalties, fees, or other charges awarded to any party) shall be deemed the prevailing party for all purposes and shall therefore be entitled to an additional award of the full amount of the attorneys’ fees, deposition costs, and expenses paid by such prevailing party in connection with arbitration or litigation without reduction or apportionment based upon the individual claims or defenses giving rise to the fees and expenses. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Development Expenses Novartis shall be solely responsible for the costs and expenses of Developing and commercializing Licensed Products pursuant to the terms of this Agreement, except with respect to Infinity’s research, development and commercialization activities with respect to an Abandoned Profile pursuant to Section 3.3.1 (subject to Section 2.3).
Development Budget Attached hereto as Exhibit "B" and incorporated herein by this reference is the Development Budget in an amount equal to $_____________. Owner acknowledges and represents that the attached Development Budget includes the total costs and expenses to acquire, develop, renovate and construct the Real Property and the Apartment Housing.
Increased Costs and Reduced Return (a) If any Lender, any Agent or the L/C Issuer shall have determined that any Change in Law shall (i) subject such Agent, such Lender or the L/C Issuer, or any Person controlling such Agent, such Lender or the L/C Issuer to any tax, duty or other charge with respect to this Agreement or any Loan made by such Agent or such Lender or any Letter of Credit issued by the L/C Issuer, or change the basis of taxation of payments to such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer of any amounts payable hereunder (except for Indemnified Taxes and Excluded Taxes), (ii) impose, modify or deem applicable any reserve, special deposit or similar requirement against any Loan, any Letter of Credit or against assets of or held by, or deposits with or for the account of, or credit extended by, such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer or (iii) impose on such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer any other condition regarding this Agreement or any Loan or Letter of Credit, and the result of any event referred to in clauses (i), (ii) or (iii) above shall be to increase the cost to such Agent, such Lender or the L/C Issuer of making any Loan, issuing, guaranteeing or participating in any Letter of Credit, or agreeing to make any Loan or issue, guaranty or participate in any Letter of Credit, or to reduce any amount received or receivable by such Agent, such Lender or the L/C Issuer hereunder, then, upon demand by such Agent, such Lender or the L/C Issuer, the Borrowers shall pay to such Agent, such Lender or the L/C Issuer such additional amounts as will compensate such Agent, such Lender or the L/C Issuer for such increased costs or reductions in amount; provided, however, that notwithstanding anything to the contrary in this Section 2.10(a), it shall be a condition to a Lender’s or L/C Issuer’s exercise of its rights, if any, under this Section 2.10(a) that such Lender or L/C Issuer shall generally be exercising similar rights with respect to borrowers under similar agreements.
