Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
System Upgrade Facilities and System Deliverability Upgrades Connecting Transmission Owner shall design, procure, construct, install, and own the System Upgrade Facilities and System Deliverability Upgrades described in Appendix A hereto. The responsibility of the Developer for costs related to System Upgrade Facilities and System Deliverability Upgrades shall be determined in accordance with the provisions of Attachment S to the NYISO OATT.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Participating TO's Interconnection Facilities Construction The Participating TO's Interconnection Facilities shall be designed and constructed in accordance with Good Utility Practice. Upon request, within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Participating TO and Interconnection Customer agree on another mutually acceptable deadline, the Participating TO shall deliver to the Interconnection Customer and the CAISO the following “as-built” drawings, information and documents for the Participating TO's Interconnection Facilities [include appropriate drawings and relay diagrams]. The Participating TO will obtain control for operating and maintenance purposes of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades upon completion of such facilities. Pursuant to Article 5.2, the CAISO will obtain Operational Control of the Stand Alone Network Upgrades prior to the Commercial Operation Date.
Participating TO’s Interconnection Facilities The Participating TO shall design, procure, construct, install, own and/or control the Participating TO’s Interconnection Facilities described in Appendix A at the sole expense of the Interconnection Customer. Unless the Participating TO elects to fund the capital for the Participating TO’s Interconnection Facilities, they shall be solely funded by the Interconnection Customer.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Facility Use The Employer shall allow individuals the use of gender- segregated facilities, such as restrooms, locker rooms, and dressing rooms that are consistent with that individual's gender expression or gender identity. In such facilities where undressing in the presence of others occurs, the Employer shall allow access to and use of a facility consistent with that individual's gender expression or gender identity.
CAISO Monthly Billed Fuel Cost [for Geysers Main only] The CAISO Monthly Billed Fuel Cost is given by Equation C2-1. CAISO Monthly Billed Fuel Cost Equation C2-1 = Billable MWh ◆ Steam Price ($/MWh) Where: • Steam Price is $16.34/MWh. • For purposes of Equation C2-1, Billable MWh is all Billable MWh Delivered after cumulative Hourly Metered Total Net Generation during the Contract Year from all Units exceeds the Minimum Annual Generation given by Equation C2-2. Equation C2-2 Minimum Annual Generation = (Annual Average Field Capacity ◆ 8760 hours ◆ 0.4) - (A+B+C) Where: • Annual Average Field Capacity is the arithmetic average of the two Field Capacities in MW for each Contract Year, determined as described below. Field Capacity shall be determined for each six-month period from July 1 through December 31 of the preceding calendar year and January 1 through June 30 of the Contract Year. Field Capacity shall be the average of the five highest amounts of net generation (in MWh) simultaneously achieved by all Units during eight-hour periods within the six-month period. The capacity simultaneously achieved by all Units during each eight-hour period shall be the sum of Hourly Metered Total Net Generation for all Units during such eight-hour period, divided by eight hours. Such eight-hour periods shall not overlap or be counted more than once but may be consecutive. Within 30 days after the end of each six-month period, Owner shall provide CAISO and the Responsible Utility with its determination of Field Capacity, including all information necessary to validate that determination. • A is the amount of Energy that cannot be produced (as defined below) due to the curtailment of a Unit during a test of the Facility, a Unit or the steam field agreed to by CAISO and Owner. • B is the amount of Energy that cannot be produced (as defined below) due to the retirement of a Unit or due to a Unit’s Availability remaining at zero after a period of ten Months during which the Unit’s Availability has been zero. • C is the amount of Energy that cannot be produced (as defined below) because a Force Majeure Event reduces a Unit’s Availability to zero for at least thirty (30) days or because a Force Majeure Event reduces a Unit’s Availability for at least one hundred eighty (180) days to a level below the Unit Availability Limit immediately prior to the Force Majeure Event. • The amount of Energy that cannot be produced is the sum, for each Settlement Period during which the condition applicable to A, B or C above exists, of the difference between the Unit Availability Limit immediately prior to the condition and the Unit Availability Limit during the condition.
