Corrections of errors, defect and omissions Sample Clauses

Corrections of errors, defect and omissions. Contractor agrees to perform the work as may be necessary to correct errors, defects, and omissions in the services required under this Contract, without undue delays and without cost to COG. The acceptance of the work set forth herein by COG shall not relieve the Contractor of the responsibility of subsequent corrections of such errors.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Corrections of errors, defect and omissions. Contractor agrees to perform the work as may be necessary to correct errors, defects, and omissions in the services required under this Contract, without undue delays and without cost to the County. The acceptance of the work set forth herein by the County shall not relieve the Contractor of the responsibility of subsequent corrections of such errors.
Sample 1Sample 2Sample 3See All (6)
Corrections of errors, defect and omissions. Contractor agrees to perform the work as may be necessary to correct errors, defects, and omissions in the services required under this Contract, without undue delays and without cost to MWCOG and/or members. The acceptance of the work set forth herein by MWCOG and/or members shall not relieve the Contractor of the responsibility of subsequent corrections of such errors.
Sample 1

Related to Corrections of errors, defect and omissions

  • Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.

  • Professional Liability (Errors & Omissions Insurance with limits of not less than $1,000,000 each occurrence, $2,000,000 aggregate. Such insurance will cover all professional services rendered by or on behalf of PROVIDER and its subcontractors under this Agreement. Renewal policies written on a claims- made basis will maintain the same retroactive date as in effect at the inception of this Agreement. If coverage is written on a claims-made basis, PROVIDER agrees to purchase an Extended Reporting Period Endorsement, effective for two (2) full years after the expiration or cancellation of the policy. No professional liability policy written on an occurrence form will include a sunset or similar clause that limits coverage unless such clause provides coverage for at least three (3) years after the expiration of cancellation of this Agreement.

  • Professional Liability (Errors and Omissions) For consultant contracts, insurance appropriate to Consultant’s profession, with limit no less than $1,000,000 per occurrence or claim, $2,000,000 aggregate. If Contractor maintains broader coverage and/or higher limits than the minimums shown above, City requires and shall be entitled to the broader coverage and/or the higher limits maintained by Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to City.

  • PROFESSIONAL LIABILITY INSURANCE (ERRORS & OMISSIONS) Professional Liability Insurance for Errors and Omissions coverage in the amount of not less than ($1,000,000). If CONTRACTOR sub-contracts in support of CONTRACTOR’S work provided for in the agreement, Professional Liability Insurance for Errors shall be provided by the sub-contractor in an amount not less than one million dollars ($1,000,000) in aggregate. The insurance coverage provided by the CONTRACTOR shall contain language providing coverage up to one (1) year following completion of the contract in order to provide insurance coverage for the hold harmless provisions herein if the policy is a claims-made policy.

  • Errors/Omissions The Engineer shall make revisions to the work authorized in this contract which are necessary to correct errors or omissions appearing therein, when required to do so by the State. No additional compensation shall be paid for this work.

  • Technology Errors and Omissions The Contractor shall maintain during the term of the Contract Technology Errors and Omissions Insurance for claims for damages arising from computer related services including, but not limited to, the following: consulting, data processing, programming, system integration, software development, installation, distribution or maintenance, systems analysis or design, training, staffing or other support services, any electronic equipment, computer software developed, manufactured, distributed, licensed, marketed or sold. If the policy is written on a claims made basis, Contractor must provide to OGS proof that the policy provides the option to purchase an Extended Reporting Period (“tail coverage”) providing coverage for no less than one (1) year after work is completed in the event that coverage is cancelled or not renewed. This requirement applies to both primary and excess liability policies, as applicable.

  • Errors and Omissions All reports, files and other documents prepared and submitted by Contractor shall be complete and shall be carefully checked by the professional(s) identified by Contractor as project manager and key personnel attached hereto, prior to submission to the County. Contractor agrees that County review is discretionary and Contractor shall not assume that the County will discover errors and/or omissions. If the County discovers any errors or omissions prior to approving Contractor’s reports, files and other written documents, the reports, files or documents will be returned to Contractor for correction. Should the County or others discover errors or omissions in the reports, files or other written documents submitted by the Contractor after County approval thereof, County approval of Contractor’s reports, files or documents shall not be used as a defense by Contractor in any action between the County and Contractor, and the reports, files or documents will be returned to Contractor for correction.

  • Products and Completed Operations Personal Injury Liability Contractual Liability The policy shall be on an occurrence form and limits shall not be less than: $1,000,000 Each Occurrence $2,000,000 General Aggregate $1,000,000 Products/Completed Operations Aggregate $1,000,000 Personal & Advertising Injury Automotive Liability: The Party shall carry automotive liability insurance covering all motor vehicles, including hired and non-owned coverage, used in connection with the Agreement. Limits of coverage shall not be less than $500,000 combined single limit. If performance of this Agreement involves construction, or the transport of persons or hazardous materials, limits of coverage shall not be less than $1,000,000 combined single limit.

  • Excess/Umbrella Liability Policies Required insurance coverage limits may be provided through a combination of primary and excess/umbrella liability policies. If coverage limits are provided through excess/umbrella liability policies, then a Schedule of underlying insurance listing policy information for all underlying insurance policies (insurer, policy number, policy term, coverage and limits of insurance), including proof that the excess/umbrella insurance follows form must be provided after renewal and/or upon request.

  • Professional Liability (Errors and Omissions) Insurance Limits shall not be less than the following:

Time is Money Join Law Insider Premium to draft better contracts faster.