Project Planning GOVERNMENTAL APPROVALS; ENVIRONMENTAL COMPLIANCE; PUBLIC INFORMATION 30 4.1 Planning and Engineering Activities 30 4.2 Site Conditions 30 4.3 Governmental Approvals 30 4.4 Environmental Compliance 34 4.5 Community Outreach and Public Information 35
Strategic Planning Facilitate the effective alignment of IT requirements/ Information Resource Management (IRM) plans with strategic business plans and program initiatives. Management Improvements: Development and implementation of improved systems and business practices to optimize productivity and service delivery operations (e.g., analysis, and implementation of improvements in the flow of IT work and program processes and tool utilization, including business system analysis, identification of requirements for streamlining, re-engineering, or re-structuring internal systems/business processes for improvement, determination of IT solution alternatives, benchmarking).
INTERNET PLANNING, ENGINEERING AND OPERATIONS Job Title: Internet/Web Engineer Job#: 2620 General Characteristics Integrally involved in the development and support of all Internet/Intranet/Extranet sites and supporting systems. Works closely with other IT groups and customers to define the system design and user interface based on customer needs and objectives. Participates in all phases of the development and implementation process, and may act as a project manager on special projects. Ensures the integration of the Web servers and all other supporting systems. Responsible for system tuning, optimization of information/data processing, maintenance and support of the production environment.
Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
Selection Planning Prior to the issuance to consultants of any requests for proposals, the proposed plan for the selection of consultants under the Project shall be furnished to the Association for its review and approval, in accordance with the provisions of paragraph 1 of Appendix 1 to the Consultant Guidelines. Selection of all consultants’ services shall be undertaken in accordance with such selection plan as shall have been approved by the Association, and with the provisions of said paragraph 1.
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $696,243.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Curriculum Development This includes the analysis and coordination of textual materials; constant review of current literature in the field, some of which are selected for the college library collection, the preparation of selective, descriptive materials such as outlines and syllabi; conferring with other faculty and administration on curricular problems; and, the attendance and participation in inter and intra-college conferences and advisory committees.
Development cooperation 1. The Parties recognise that development cooperation is a crucial element of their Partnership and an essential factor in the realisation of the objectives of this Agreement as laid down in Article 1. This cooperation can take financial and non-financial forms.
Development Services During the term of this Agreement, the Provider agrees to provide to or on behalf of the Port the professional services and related items described in Exhibit A (collectively, the “Development Services”) in accordance with the terms and conditions of this Agreement. The Provider specifically agrees to include at least one Port representative in any economic development negotiations or discussions in which the Provider is involved concerning (i) a port-related business prospect or (ii) a business transaction which will ultimately require Port involvement, financial or otherwise.
