Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Approval and Completion If any dispute regarding the design of the Tenant Improvements is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable out of the TI Fund (as defined in Section 5(d) below), and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems (in which case Landlord shall make the final decision). Any changes to the TI Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof.
Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.
Existing Improvements The existing Improvements, if any, were constructed, and are being used and maintained, in accordance with all applicable Laws, including zoning Laws.
Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Removal of Improvements Except as otherwise expressly agreed to by Lessor and Lessee, Lessee shall have the right to remove all Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property installed by Lessee from the Premises upon the termination or expiration of this Lease, but in no event later than the date that is 120 days following the expiration or termination of this Lease (the “Removal Date”) and Lessor shall provide Lessee with access to the Premises at reasonable times until expiration of the Removal Date for the purpose of removing such items. Lessee shall provide Lessor with written notice of its election to remove the Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property from the Premises at least 60 days prior to the expiration of the Lease. If Lessee elects to remove the Tank Farm Assets and Improvements from the Premises after such removal Lessee shall restore any damage to the Premises and clean the Premises so as to eliminate therefrom any accumulation (other than any de minimis and non-hazardous accumulation) of foreign substances, materials, or debris, in addition to any Environmental Cleanup that may be required under Article 10. Lessee shall pay Lessor pro rata Rent (based on the amount of Rent applicable during the last month prior to the termination or expiration) through the date of Lessee’s complete removal of all such items. During the period of such removal and clean-up, all terms and conditions of this Lease, including, the indemnity and insurance provisions shall continue in full force and effect. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date, and provided that such facilities are in good working condition at the expiration of the Term (ordinary wear and tear excepted) then, such Tank Farm Assets and Improvements shall be deemed permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date and such facilities are not in good working condition at the expiration of the term (ordinary wear and tear excepted), or Lessee fails to so remove any or all of the Tank Farm Assets and Improvements from the Premises before the Removal Date, then, in addition to all rights and remedies available at law or in equity, without any prior notice, Lessor may (but shall be under no obligation), at Lessor’s option, deem such Tank Farm Assets and Improvements to be permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee, and Lessee shall reimburse Lessor for all costs of such removal and disposal upon demand from Lessor. If requested by Lessor, Lessee shall execute any and all documents necessary to evidence that title to the Tank Farm Assets and Improvements that Lessee does not remove by the Removal Date is in Lessor and to extinguish and remove any cloud or potential cloud on the title to the Premises and/or such facilities created by Lessee.
