Acquisition of Lands for Park Purposes Sample Clauses

Acquisition of Lands for Park Purposes. The streamlined review process may be used for the acquisition of land for park purposes, including additions to the park. Stipulation III.C – Identifying Historic Properties within APE of this PA does not apply to this activity provided the acquisition does not include any further treatment or alteration of newly acquired lands, because access to land for inventory and evaluation prior to NPS acquisition may be limited. This does not relieve the park of Section 110 inventory responsibilities after acquisition. The park shall protect any known or potential historic properties on the land acquired from demolition by neglect. Pursuant to 36 CFR § 800.5(a)(2)(vi), demolition by neglect constitutes an adverse effect. Undertakings proposed in conjunction with the acquisition that have the potential to adversely affect historic properties, must be reviewed per 36 CFR Part 800.
Sample 1
AutoNDA by SimpleDocs
Acquisition of Lands for Park Purposes. The Streamlined Review Process may be used for the acquisition of land for park purposes, including additions to existing parks. The second criterion for use of the Streamlined Review Process (identification and evaluation of all types of historic properties within the project APE; see Section III.A.2) does not apply to this activity, provided the acquisition does not include any further treatment or alteration of properties, since access to land for inventory and evaluation prior to NPS acquisition may be limited. Any known or potential historic properties on the land acquired should be protected from demolition by neglect. Pursuant to 36 CFR 800.5(a)(2)(vi), demolition by neglect constitutes an adverse effect. If any undertakings are proposed in conjunction with the acquisition that have the potential to affect historic properties, the Streamlined Review Process may not be used.
Sample 1

Related to Acquisition of Lands for Park Purposes

  • CONSTRUCTION AND RENOVATION Construction of academic or residential buildings on the UC Berkeley campus may be scheduled for the term of this Lease in the vicinity of the apartments. Capital improvement and other major housing construction or repair projects will necessarily cause increased noise and dust in affected and nearby residences at certain times. There is the possibility of both planned and unplanned utility shutdowns and access to certain facilities, streets, parking lots, walking, and bike pathways may be limited, rerouted, or completely restricted. The University will work with building contractors to make every effort to minimize construction inconveniences. By agreeing to this Lease Agreement, the Resident acknowledges notice of the possibility of scheduled construction and access limitations, and acknowledges that there will be disturbances, disruptions, and inconveniences resulting from such constructions and has agreed to such. The Resident also acknowledges that increased noise, dust, potential reassignment, or loss of parking spaces related to construction or renovation are not grounds for cancellation or termination of this Lease.

  • Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • BUSINESS PURPOSE The Company may conduct any and all lawful business appropriate in carrying out the Company’s objectives, as permitted under Section 00-00-000 of the Act.

  • POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

  • POSSESSION OF THE APARTMENT 7.1. Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the common areas to the Association of Allottees is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on June 2023, unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project ("Force Majeure"). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date. The Promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

  • CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.

  • Construction of Public Improvements a. Upon satisfaction of the conditions set forth in Paragraph 2.1 and the notice requirement set forth below, Developer shall construct the Public Improvements at its own expense in accordance with this Agreement, the Final Plat, the Resolution, the Civil Engineering Construction Plans, the Town’s ordinances, resolutions and regulations and all other applicable laws and regulations. All Public Improvements shall be installed and constructed within the rights- of-way or easements dedicated to the Town. Unless otherwise approved by the Town in writing, all materials used for constructing the Public Improvements shall be materials set forth on the Town’s approved material list. Workmanship and materials shall be of good quality.

  • Execution of the Project Section 3.01. (a) The Borrower declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project with due diligence and efficiency and in conformity with appropriate financial, engineering, public utility and environmental practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project.

Time is Money Join Law Insider Premium to draft better contracts faster.