POSSESSION OF THE APARTMENT/PLOT Sample Clauses

POSSESSION OF THE APARTMENT/PLOT. 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF THE APARTMENT/PLOT. 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on
POSSESSION OF THE APARTMENT/PLOT. 7.1 Schedule for possession of the said Designated Apartment-
POSSESSION OF THE APARTMENT/PLOT. 7.1 The promoter shall give possession of the apartment/flat to the allottee on or before DD/MM/YEAR (“Possession Date”). Provided however, that the promoter shall be entitled to extension of time for giving delivery of the apartment/flat on the possession date, if the completion of the real Estate Project is delayed on account of any or all of the following factors: • Any force Majure Events; • Any notice, order, rule, notification, of the governement and/or by any other public or competent authority/court; • Any stay order / injunction order issued by any court of law, competent authority , BMC, Statutory authority ; • Any other circumstances that may deemed reasonable by the authority.
POSSESSION OF THE APARTMENT/PLOT 

Related to POSSESSION OF THE APARTMENT/PLOT

  • POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

  • Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .

  • CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.

  • Construction Phase - Administration of the Construction Contract 1.6.1 The Construction Phase shall commence with the acceptance of the Construction Manager’s Guaranteed Maximum Price (or acceptance of a partial Guaranteed Maximum Price for a stage or phase) and issuance of a Notice to Proceed with Construction Services and terminate sixty (60) days after Final Payment to the Contractor is made, or when all of Architect/Engineer’s services have been satisfactorily performed, whichever occurs later.

  • GENERAL COMPLIANCE WITH RESPECT TO THE APARTMENT 15.1 Subject to para 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the [Apartment/Plot] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the [Apartment/Plot], or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the [Apartment/Plot] and keep the [Apartment/Plot], its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized.

  • Execution of the Project Section 2.01. (a) The Federation declares its commitment to the objectives of the Project as set forth in Schedule 2 to the Development Credit Agreement, and, to this end, shall, carry out the Project with due diligence and efficiency and in conformity with appropriate administrative, financial, technical and environmental practices, and shall provide, or cause to be provided, promptly as needed, the funds, facilities, services and other resources required for the Project.

  • DESCRIPTION OF THE PROPERTY 14.1 The property as referred to in the Proclamation of Sale shall be deemed to have been correctly and sufficiently described.