Physical Delivery All notices must be in writing, except as provided in § 27.2. Any document, including a signed 698 document or notice, from or on behalf of Seller, and delivered to Buyer is effective when physically received by Buyer, any 699 signatory on behalf of Buyer, any named individual of Buyer, any representative of Buyer, or Brokerage Firm of Broker working 700 with Buyer (except for delivery, after Closing, of the notice requesting mediation described in § 23 and except as provided in 701 § 27.2). Any document, including a signed document or notice, from or on behalf of Buyer, and delivered to Seller is effective 702 when physically received by Seller, any signatory on behalf of Seller, any named individual of Seller, any representative of Seller, 703 or Brokerage Firm of Broker working with Seller (except for delivery, after Closing, of the notice requesting mediation described 704 in § 23 and except as provided in § 27.2).
Personal Delivery When personally delivered to the recipient, notice is effective upon delivery.
Acceptance Period For all Services provided under this Agreement, Vendor grants to Citizens a thirty (30) calendar day acceptance period ("Acceptance Period") commencing on the date completed Services are delivered to Citizens. Citizens shall have the right to reject the Services, in whole or in part, during the Acceptance Period for Vendor’s failure to meet the specifications associated with the delivered Services, with such determination to be made in Citizens’ reasonable judgment. At the end of the Acceptance Period, if Citizens has not rejected the Services, the Services shall be deemed to be accepted by Citizens; provided, however, that Citizens’ acceptance of the Services shall not be deemed a waiver of any of Citizens’ warranty rights as expressly provided in this Agreement.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Material Delivery Within 60 days after award date, Purchaser shall provide Forest Service a written schedule showing the desired delivery dates of any material to be supplied by Forest Service. With reasonable notice, schedule may be amended by agreement. Forest Service agrees to make delivery within 15 days after the scheduled delivery dates that are at least 60 days after the schedule is submitted, unless prevented by causes beyond control of Forest Service. If Purchaser does not provide Forest Service the written schedule within the period provided in this Subsection, Forest Service agrees to make delivery within 90 days after a late schedule is submitted, unless prevented by causes beyond control of Forest Service. After delivery to and written receipt by Purchaser, Purchaser is responsible for installation of needed material and for any loss of or damage to such material due to Purchaser's negligence prior to installation or return of unused material to Forest Service. At Purchaser’s option, Forest Service deliveries shall be to Purchaser’s storage area, as agreed, or to the nearest practicable point to the job site along existing roads. Unused material shall be returned to Forest Service at location of delivery, unless agreed otherwise.
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
361 Acceptance of Specified Roads Specified Road work may be accepted subject to completion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Purchaser, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Purchaser, such as seasonal limitations. Purchaser shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when application is not necessary to prevent dusting of the road surface due to climatic conditions. Purchaser shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Purchaser in connection with Purchaser’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
No Transmission Delivery Service The execution of this Agreement does not constitute a request for, nor agreement to provide, any Transmission Service under the NYISO OATT, and does not convey any right to deliver electricity to any specific customer or Point of Delivery. If Developer wishes to obtain Transmission Service on the New York State Transmission System, then Developer must request such Transmission Service in accordance with the provisions of the NYISO OATT.
Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
C4 Contract Price During Extension of the Initial Contract Period C4.1 Subject to the Pricing Schedule and the provision in clause F6 (Variation), the Contract Price shall apply for the Initial Contract Period and following an extension pursuant to clause F8 (Extension of Initial Contract Period), to the date of expiry of the extended period, or such earlier date of termination or partial termination of the agreement in accordance with the Law or the provisions of the Contract. C5 Euro
