Allowed Delay has the meaning set forth in Section 2(c)(ii).
Notice Event means any of the events enumerated in paragraph (b)(5)(i)(C) of the Rule and listed in Section 4(a) of this Disclosure Agreement.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
End of Suspension Notice has the meaning set forth in Section 1(f)(ii).
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Extension Minimum Condition means a condition to consummating any Extension that a minimum amount (to be determined and specified in the relevant Extension Request, in the Borrower’s sole discretion) of any or all applicable Classes be submitted for Extension.
Permitted Number means one (1) unless otherwise indicated under a valid license (e.g. volume license) granted by Investintech or agreed to in writing by Investintech.
Delay Event means any event set out at Clause 5.19.4 [Delay Events].
Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.
Non-Extension Notice has the meaning specified in Section 2.10.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Increased Facility Activation Notice a notice substantially in the form of Exhibit G.
Penalty Notice means a written no- tification from the Director informing a respondent that the Director has made a finding of violation and, absent a request for a hearing, will impose a civil monetary penalty.
Non-Extension Notice Date has the meaning specified in Section 2.03(b)(iii).
Extension Notice has the meaning specified in Section 308.
Suspension Notice As defined in Section 6(d) hereof.
Availability Notice has the meaning given to it in the Grid Code;
Revocation or suspension notice means a board notification suspending a license for an indefinite or specified period of time or a notification revoking a license as required by the Act.
Permitted Amount means, on any date, an amount equal to 3.5 times Adjusted EBITDA as of the most recent fiscal quarter for which financial statements of the Company are internally available immediately preceding such date.
Rectification Notice means a notice in writing that identifies a defect in a work and requires rectification of the defect within a specified period of time.
Reduction Notice has the meaning set forth in Section 1.3.
Cure Deadline shall have the meaning provided in Section 11.11(a).
Supply Failure has the meaning given to it in Section 7.5.2 (Supply Failure).
Required Notice Period means the number of days required notice set forth below applicable to the Aggregate Reduction indicated below: Aggregate Reduction Required Notice Period £$100,000,000 two Business Days >$100,000,000 to $250,000,000 five Business Days ³$250,000,000 ten Business Days
Delay Period shall have the meaning set forth in Section 5 hereof.