Defects Liability Period means the warranty period following the taking over, during which the Contractor is responsible for making good, defects and damage in Goods and Services provided, under the Contract.
Defect Liability Period in relation to a work means the specified period from the date of COMPLETION CERTIFICATE upto the date of issue of FINAL CERTIFICATE during which the CONTRACTOR stands responsible for rectifying all defects that may appear in the works executed by the CONTRACTOR in pursuance of the CONTRACT and includes warranties against Manufacturing/Fabrication/ Erection/Construction defects covering all materials plants, equipment, components, and the like supplied by the CONTRACTOR, works executed against workmanship defects.
Warranty Period /„Maintenance Period‟ shall mean the period during which the Contractor shall remain liable for repair or replacement of any defective part of the Works performed under the Contract.
Extended Warranty means an agreement for a specified duration to
Improvement warranty period means a period:
Defects Liability Expiry Certificate means the certificate to be issued by the Client to the Contractor, in accordance with the Contract.
Indemnity Period means the period during which the results of the business are affected beginning with the occurrence of the monetary win but not exceeding the maximum indemnity period
Product Warranty has the meaning set forth in Section 9.3.
Manufacturer’s Warranty means the warranty supplied from time to time by the manufacturer of the Goods as at the date of the acceptance of the Statement of Work; “PPSA” means the Personal Property Securities Xxx 0000; “Price” means the amount specified within each Statement of Work (subject to any Variation) or as otherwise specified from the Company to the Customer representing the cost for the Works; “Related Work” means any additional building, carpentry, painting, plastering, plumbing or other work or other trades that the Customer requires, which are not to be carried out by the Company; “Services” means the services provided by the Company to the Customer as part of the Works, which may include without limitation the installation of Goods; “Services Delay Charge” means the services delay charge (if any) set out in the Statement of Work; “Services Interruption Event” means any interruption to a Works caused by; a Force Majeure Event, the Customer’s failure to carry out or perform any obligation required of it under this agreement which in the sole opinion of the Company does or may cause a delay in the Works and any other matter which in the reasonable opinion of the Company will cause an interruption or delay in the performance of the Works; “Statement of Work” means the details outlining the provision of the Works, which statement can be delivered verbally or in writing (including email) and may include (where applicable) an estimate or quotation (as specifically expressed as the case) of costs; “Variation” means a change in the Statement of Work including the specifications, scope, time of supply, price or scale of the Works and such variation shall form part of this agreement; “Workmanship” means a good and high quality and standard of delivery in connection with the Services performed; “Works” means the supply of Goods and the provision of Services to the Customer as per each Statement of Work;
Maximum Liability has the meaning assigned to such term in Section 10.10.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Penalty Period has the meaning set forth in Section 6.3.
Products Liability means:Your legal liability in respect of Personal Injury and/or Property Damage caused by or arising out of any Products or the reliance upon a representation or warranty made at any time with respect to such products; but only where such Personal Injury and/or Property Damage occurs away from premises owned or leased by or rented to You and after physical possession of such products has been relinquished to others.
Seller’s Warranties means the warranties given by the Seller pursuant to Clause 9 and Schedule 9, and “Seller’s Warranty” means any one of them;
Minimum Essential Coverage has the meaning given in the Affordable Care Act, 26 U.S.C. §5000A(f).
Product Liability means any liability, claim or expense, including but not limited to attorneys’ fees and medical expenses, arising in whole or in part out of a breach of any express or implied product warranty by the Company, strict liability in tort, negligent manufacture of product, negligent provision of services, product recall, or any other allegation of liability arising from the design, testing, manufacture, packaging, labeling (including instructions for use), or sale of products.
Survival Period has the meaning set forth in Section 11.1.
Confidentiality Period means, (A) with respect to Confidential Information (other than trade secrets), during the term of the Service Term and for a period of one (1) year after termination of the Service Term, and (B) with respect to trade secrets, during the term of the Service Term and for such period thereafter as the information in question falls within the definition of trade secrets under prevailing law.
Product Liability Claim means a Claim of a Third Party (other than a Claim arising out of use of the Product in a clinical trial) that (i) arises as a result of the use of the Product during the Term that results in personal injury or death or (ii) is in anticipation of or intended to prevent or forestall personal injury or death as a result of the use of the Product during the Term.
Defects Liability Certificate means the certificate issued by Architect upon correction of defects by the Contractor.
Latent Defects means such defects caused by faulty designs, material or work-man- ship which cannot be detected during inspection, testing etc, based on the technology available for carrying out such tests.
Express warranty means an express warranty as set forth in sections 4-2-313 and 4-2.5-210, C.R.S. An express warranty shall cover every part of a new facilitative device.
Extension Minimum Condition means a condition to consummating any Extension that a minimum amount (to be determined and specified in the relevant Extension Request, in the Borrower’s sole discretion) of any or all applicable Classes be submitted for Extension.
Excluded Liability means any liability that is excluded under the Bail-In Legislation from the scope of any Bail-In Action including, without limitation, any liability excluded pursuant to Article 44 of the Bank Recovery and Resolution Directive.