Revenue Enforcement and Protection Program Sample Clauses

Revenue Enforcement and Protection Program. (REAP): Pursuant to MGL c.62C §49A, the undersigned certifies under the penalties of perjury that to the best of his/her knowledge and belief that the Designer and/or individuals in the Designer are in compliance with all laws of the commonwealth relating to taxes, reporting of employees and contractors, and withholding and remitting child support.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Revenue Enforcement and Protection Program. Pursuant to X.X. x. 62C, §49A, the undersigned hereby certifies under the penalties of perjury that Consultant's Federal Identification No. is (for corporate entities): and that to the best of his/her knowledge and belief Consultant has complied with all laws of the Commonwealth relating to taxes, the reporting of employees and contractors, and withholding and remitting of child support. In order to comply with all laws of the Commonwealth relating to taxes, the undersigned certifies that Consultant (check applicable item):
Sample 1
Revenue Enforcement and Protection Program. Pursuant to G.L.c. 62C, §49A, the undersigned hereby certifies under the penalties of perjury that Contractor’s Federal Identification No. is (for corporations only) , and that to the best of his/her knowledge and belief Contractor has complied with all laws of the Commonwealth relating to taxes, the reporting of employees and Contractors, and withholding and remitting of child support. In order to comply with all laws of the Commonwealth relating to taxes, the undersigned certifies that Contractor (check applicable item):
Sample 1
Revenue Enforcement and Protection Program. (REAP): Pursuant to Mass. G.L. ch. 62C, § 49A, the undersigned certifies under the penalties of perjury that to the best of his/her knowledge and belief that the OPM and the principals thereof are in compliance with all laws of the commonwealth relating to taxes, reporting of employees and contractors, and withholding and remitting child support.
Sample 1
Revenue Enforcement and Protection Program. (REAP): Pursuant to Massachusetts General Laws, Chapter 62C, Section 49A, the undersigned certifies under the penalties of perjury that to the best of his/her knowledge and belief that the Owner’s Project Manager and the principals thereof are in compliance with all laws of the Commonwealth relating to taxes, reporting of employees and contractors, and withholding and remitting child support.
Sample 1

Related to Revenue Enforcement and Protection Program

  • ADDITIONAL ENFORCEMENT ACTIONS Upon a determination by the Director that there is a threat to the public health or the environment, or upon discovery of any new information, RIDEM reserves the right to take additional enforcement actions as provided by law or regulation, including, but not limited to, the issuance of “Immediate Compliance Orders” as authorized by R.I. Gen. Laws Section 42-17.1- 2(21). This Agreement shall not restrict any right to hearing or other right available by statute or regulation that the Respondents may have regarding any new enforcement action commenced by RIDEM after the execution of this Agreement.

  • Collaboration on Compliance and Enforcement A Competent Authority will notify the other Competent Authority when the first-mentioned Competent Authority has reason to believe that an error may have led to incorrect or incomplete information reporting or there is non-compliance by a Reporting Financial Institution with the applicable reporting requirements and due diligence procedures consistent with the Common Reporting Standard. The notified Competent Authority will take all appropriate measures available under its domestic law to address the errors or non-compliance described in the notice.

  • General Enforcement Authority That the terms of this Agreement shall be enforced in accordance with the provisions, terms and authorities provided in this Agreement and under the respective laws and regulations of each Participating State.

  • Compliance and Enforcement If Contractor willfully fails to comply with any of the provisions of the LBE Ordinance, the rules and regulations implementing the LBE Ordinance, or the provisions of this Agreement pertaining to LBE participation, Contractor shall be liable for liquidated damages in an amount equal to Contractor’s net profit on this Agreement, or 10% of the total amount of this Agreement, or $1,000, whichever is greatest. The Director of the City’s Human Rights Commission or any other public official authorized to enforce the LBE Ordinance (separately and collectively, the “Director of HRC”) may also impose other sanctions against Contractor authorized in the LBE Ordinance, including declaring the Contractor to be irresponsible and ineligible to contract with the City for a period of up to five years or revocation of the Contractor’s LBE certification. The Director of HRC will determine the sanctions to be imposed, including the amount of liquidated damages, after investigation pursuant to Administrative Code §14B.17. By entering into this Agreement, Contractor acknowledges and agrees that any liquidated damages assessed by the Director of the HRC shall be payable to City upon demand. Contractor further acknowledges and agrees that any liquidated damages assessed may be withheld from any monies due to Contractor on any contract with City. Contractor agrees to maintain records necessary for monitoring its compliance with the LBE Ordinance for a period of three years following termination or expiration of this Agreement, and shall make such records available for audit and inspection by the Director of HRC or the Controller upon request.

  • Specific Enforcement Each party hereto acknowledges that the remedies at law of the other parties for a breach or threatened breach of this Agreement would be inadequate and, in recognition of this fact, any party to this Agreement, without posting any bond, and in addition to all other remedies that may be available, shall be entitled to obtain equitable relief in the form of specific performance, a temporary restraining order, a temporary or permanent injunction or any other equitable remedy that may then be available.

  • Contract Enforcement Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED TO A, B2, 5-7. Enforcement of Contract and Dispute Resolution Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED

  • Construction and Enforcement This Agreement shall be construed in accordance with the laws of the State of Florida, without and application of the principles of conflicts of laws. If it becomes necessary for any party to institute legal action to enforce the terms and conditions of this Agreement, and such legal action results in a final judgment in favor of such party ("Prevailing Party"), then the party or parties against whom said final judgment is obtained shall reimburse the Prevailing Party for all direct, indirect or incidental expenses incurred, including, but not limited to, all attorney's fees, court costs and other expenses incurred throughout all negotiations, trials or appeals undertaken in order to enforce the Prevailing Party's rights hereunder. Any suit, action or proceeding with respect to this Agreement shall be brought in the state or federal courts located in St. Lucie County in the State of Florida. The parties hereto hereby accept the exclusive jurisdiction and venue of those courts for the purpose of any such suit, action or proceeding. The parties hereto hereby irrevocably waive, to the fullest extent permitted by law, any objection that any of them may now or hereafter have to the laying of venue of any suit, action or proceeding arising out of or relating to this Agreement or any judgment entered by any court in respect thereof brought in St. Lucie County, Florida, and hereby further irrevocably waive any claim that any suit, action or proceeding brought in St. Lucie County, Florida, has been brought in an inconvenient forum.

  • Child Support Enforcement Requirements Contractor is required to comply with the child support enforcement requirements of the County. Failure of the Contractor to comply with all federal, state, and local reporting requirements for child support enforcement or to comply with all lawfully served Wage and Earnings Assignment Orders and Notices of Assignment shall constitute a material breach of the Contract. Failure to cure such breach within 60 calendar days of notice from the County shall constitute grounds for termination of the Contract.

  • County of Orange Child Support Enforcement In order to comply with the child support enforcement requirements of the County of Orange, within ten (10) days of notification of selection of award of CONTRACT but prior to official award of CONTRACT, the selected CONTRACTOR agrees to furnish to the CONTRACT MANAGER, the Purchasing Agent, or the agency/department deputy purchasing agent:

  • JOB NOTIFICATION AND ENFORCEMENT 4.1 The Employer shall forward a job notification to the appropriate International Union Representative designated by the Union for the area involved and a copy for the Local Union(s) having territorial jurisdiction, immediately upon his knowledge of all work to be done by the Employer and all subcontractors under the terms and conditions of this Agreement. The Union will designate the Local Union(s) which will have territorial jurisdiction. The job notification form to be used is attached to this Agreement as Addendum A.

Time is Money Join Law Insider Premium to draft better contracts faster.