Settlement Amount If the Non-Defaulting Party has declared an Early Termination Date pursuant to Section 7.2(b), the Non-Defaulting Party shall have the right to (i) accelerate all amounts owing between the Defaulting Party and the Non-Defaulting Party and to liquidate and terminate the undertakings set forth in this Agreement as between the Defaulting Party and the Non-Defaulting Party; and (ii) withhold any payments due to the Defaulting Party under this Agreement pending payment of the Termination Payment. The Non-Defaulting Party will calculate, in a commercially reasonable manner, the Settlement Amount with respect to the Defaulting Party’s obligations under the Agreement and shall net the Settlement Amount in the manner provided for in Section 7.3(c).
Amount The required additional Security shall be in an amount equal to the amount necessary to gross up fully for currently applicable federal and state income taxes the estimated Costs of Local Upgrades and Network Upgrades for which Interconnection Customer previously provided Security. Accordingly, the additional Security shall equal the amount necessary to increase the total Security provided to the amount that would be sufficient to permit the Interconnected Transmission Owner to receive and retain, after the payment of all applicable income taxes (“Current Taxes”) and taking into account the present value of future tax deductions for depreciation that would be available as a result of the anticipated payments or property transfers (the “Present Value Depreciation Amount”), an amount equal to the estimated Costs of Local Upgrades and Network Upgrades for which Interconnection Customer is responsible under the Interconnection Service Agreement. For this purpose, Current Taxes shall be computed based on the composite federal and state income tax rates applicable to the Interconnected Transmission Owner at the time the additional Security is received, determined using the highest marginal rates in effect at that time (the “Current Tax Rate”), and (ii) the Present Value Depreciation Amount shall be computed by discounting the Interconnected Transmission Owner’s anticipated tax depreciation deductions associated with such payments or property transfers by its current weighted average cost of capital.
CP Costs Payments On each Settlement Date, Seller shall pay to Agent (for the benefit of the Conduits) an aggregate amount equal to all accrued and unpaid CP Costs in respect of the outstanding Capital of each of the Conduits for the related Settlement Period in accordance with Article II.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Over-Allowance Amount The amount that is equal to the difference between (i) the amount of the Cost Proposal and (ii) the amount of the TI Allowance (less any portion thereof already disbursed by Landlord, or in the process of being disbursed by Landlord, on or before the Cost Proposal Delivery Date that is not otherwise included within the Cost Proposal) shall be referred to herein as the "Over-Allowance Amount." Tenant shall pay to Landlord (a) one-half (1/2) of such Over-Allowance Amount no later than ten (10) days after the Cost Proposal Delivery Date and (b) the other one-half (1/2) of such Over-Allowance Amount within ten (10) days after Landlord gives Tenant written notice that the construction of the Tenant Improvements is completed. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any then remaining portion of the TI Allowance, and such disbursement shall be pursuant to the same procedure as the TI Allowance. In the event that after the Cost Proposal Delivery Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or the Tenant Improvements, any additional costs which arise in connection with such revisions, changes or substitutions shall be paid by Tenant to Landlord as an addition to the Over-Allowance Amount as follows: (1) one-half (1/2) of such additional amount within five (5) days after Landlord's invoice therefor and (2) the remaining one-half (1/2) of such additional amount within five (5) days following Tenant's receipt of Landlord's written notice that the work to which the change order applies is complete. In addition, upon Landlord's determination of the actual costs incurred by or on behalf of Landlord for the TI Allowance Items, Tenant shall pay Landlord the amount, if any, by which such actual costs exceed the sum of the TI Allowance and the Over-Allowance Amount within fifteen (15) days after being billed therefor, or Landlord may, at its election, require that Tenant deposit with Landlord the full amount of such excess prior to Landlord's delivery of the Expansion Space to Tenant. No portion of the TI Allowance shall be used to pay Tenant or Tenant's agents, contractors or employees, unless and until Landlord's contractors and any other persons and entities employed by or under contract with Landlord have been paid in full.
Excess Amount The excess of the Participant's annual additions for the limitation year over the maximum permissible amount.
Pro Rata Payments Payments to the Holders shall be pro rata with other Holders who purchased Notes in the same oRering, based on the Principal Amount of each such Note. If a Holder receives a payment in excess of his, her, or its pro rata share, the excess shall be deemed to be held in trust for the benefit of other Holders.
