Use of Proceeds of the Loan Section 3.01. The Borrower shall cause the proceeds of the Loan to be applied to the financing of expenditures on the Project in accordance with the provisions of this Loan Agreement.
Application of Miscellaneous Proceeds upon Condemnation, Destruction, or Loss in Value of the Property In the event of a total taking, destruction, or loss in value of the Property, all of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument, whether or not then due, with the excess, if any, paid to Borrower. In the event of a partial taking, destruction, or loss in value of the Property (each, a “Partial Devaluation”) where the fair market value of the Property immediately before the Partial Devaluation is equal to or greater than the amount of the sums secured by this Security Instrument immediately before the Partial Devaluation, a percentage of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument unless Borrower and Lender otherwise agree in writing. The amount of the Miscellaneous Proceeds that will be so applied is determined by multiplying the total amount of the Miscellaneous Proceeds by a percentage calculated by taking (i) the total amount of the sums secured immediately before the Partial Devaluation, and dividing it by (ii) the fair market value of the Property immediately before the Partial Devaluation. Any balance of the Miscellaneous Proceeds will be paid to Borrower. In the event of a Partial Devaluation where the fair market value of the Property immediately before the Partial Devaluation is less than the amount of the sums secured immediately before the Partial Devaluation, all of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument, whether or not the sums are then due, unless Borrower and Lender otherwise agree in writing.
Payment of Project Costs The Grantee agrees that it will provide for payment of its full share of Project costs and that all costs connected with the Project will be paid by the Grantee on a timely basis.
Use of Proceeds of the Grant Section 3.01. The Recipient shall cause the proceeds of the Grant to be applied to the financing of expenditures on the Project in accordance with the provisions of this Grant Agreement.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
Payment of Principal, Interest, Escrow Items, Prepayment Charges, and Late Charges Borrower will pay each Periodic Payment when due. Borrower will also pay any prepayment charges and late charges due under the Note, and any other amounts due under this Security Instrument. Payments due under the Note and this Security Instrument must be made in U.S. currency. If any check or other instrument received by Lender as payment under the Note or this Security Instrument is returned to Lender unpaid, Lender may require that any or all subsequent payments due under the Note and this Security Instrument be made in one or more of the following forms, as selected by Lender: (a) cash; (b) money order; (c) certified check, bank check, treasurer’s check, or cashier’s check, provided any such check is drawn upon an institution whose deposits are insured by a U.S. federal agency, instrumentality, or entity; or (d) Electronic Fund Transfer. Payments are deemed received by Lender when received at the location designated in the Note or at such other location as may be designated by Lender in accordance with the notice provisions in Section 16. Lender may accept or return any Partial Payments in its sole discretion pursuant to Section 2. Any offset or claim that Borrower may have now or in the future against Lender will not relieve Borrower from making the full amount of all payments due under the Note and this Security Instrument or performing the covenants and agreements secured by this Security Instrument.
Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Application of Proceeds The Collateral Agent shall apply the proceeds of any collection, sale, foreclosure or other realization upon any Collateral, including any Collateral consisting of cash, as follows: FIRST, to the payment of all costs and expenses incurred by the Administrative Agent or the Collateral Agent (in their respective capacities as such hereunder or under any other Loan Document) in connection with such collection, sale, foreclosure or realization or otherwise in connection with this Agreement, any other Loan Document or any of the Obligations, including all court costs and the reasonable fees and expenses of its agents and legal counsel, the repayment of all advances made by the Collateral Agent or the Administrative Agent hereunder or under any other Loan Document on behalf of any Grantor and any other costs or expenses incurred in connection with the exercise of any right or remedy hereunder or under any other Loan Document; SECOND, to the payment in full of Unfunded Advances/Participations (the amounts so applied to be distributed between or among the Administrative Agent, any Swingline Lender and any Issuing Bank pro rata in accordance with the amounts of Unfunded Advances/Participations owed to them on the date of any such distribution); THIRD, to the payment in full of all other Obligations (the amounts so applied to be distributed (subject to the first proviso to Section 3.01 and clause (B) of the first proviso to Section 4.01(a)) among the Secured Parties pro rata in accordance with the amounts of the Obligations owed to them on the date of any such distribution); and FOURTH, to the Grantors, their successors or assigns, or as a court of competent jurisdiction may otherwise direct. The Collateral Agent shall have absolute discretion as to the time of application of any such proceeds, moneys or balances in accordance with this Agreement. Upon any sale of Collateral by the Collateral Agent (including pursuant to a power of sale granted by statute or under a judicial proceeding), the receipt of the Collateral Agent or of the officer making the sale shall be a sufficient discharge to the purchaser or purchasers of the Collateral so sold and such purchaser or purchasers shall not be obligated to see to the application of any part of the purchase money paid over to the Collateral Agent or such officer or be answerable in any way for the misapplication thereof.
OPERATION OF PROPERTY DURING AGREEMENT PERIOD The Seller will continue to operate the Property and any business conducted on the Property in the manner operated prior to the Agreement and will take no action that would adversely impact the Property, tenants, lender, or business, if any. Any changes, such as renting vacant space, that materially affects the Property or the Buyer's intended use will be permitted only with the Buyer's consent.
Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
