General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades,
Specific Provisions for Access Rights to Software For the avoidance of doubt, the general provisions for Access Rights provided for in this Section 9 are applicable also to Software. Parties’ Access Rights to Software do not include any right to receive source code or object code ported to a certain hardware platform or any right to receive respective Software documentation in any particular form or detail, but only as available from the Party granting the Access Rights.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Condition on delivery If a Vehicle accepted by an Authorized User is found to have been delivered with minor deviations or improper servicing, the Contractor must arrange to have the necessary work done within 48 hours (exclusive of Saturdays, Sundays and Federal or NYS Holidays) after receipt of written notification from the Authorized User and/or NYSPro. If Contractor cannot arrange to have the necessary work done within such time period, the corrections shall be made by an entity of the Authorized User’s choosing and Contractor will be required to reimburse the Authorized User for this expense within thirty (30) calendar days of request. At point of acceptance, the Vehicle shall have an odometer reading that is consistent with the miles, in distance, to the anticipated odometer mileage incurred between the OEM factory, the Contractor’s place of business, or other OEM Dealer location that is nearest to the delivery location, the Aftermarket Component Provider (if applicable), and the point of delivery. In the event that a Vehicle is delivered with an odometer reading that the Authorized User considers to be excessive, the Contractor shall be required to provide a reasonable explanation for the odometer reading. Vehicles that are delivered with an odometer reading that is considered excessive without a reasonable explanation, as determined by the Authorized User, may be rejected by the Authorized User.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
– OTHER SPECIAL CONDITIONS The following additional special conditions apply to this agreement:
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
Installation and Use Rights You may install and use any number of copies of the software on your devices.
