Making of Decisions Sample Clauses

Making of Decisions. If: the Consultant requests the Principal to consider the selection of alternative courses of action; and all information required to enable a decision to be made is provided by the Consultant or is otherwise available, the Principal must, in such reasonable time as not to delay or disrupt the carrying out of the Services, give a decision on the required course of action.
AutoNDA by SimpleDocs
Making of Decisions. If: the Subconsultant requests the Consultant to consider the selection of alternative courses of action; and all information required to enable a decision to be made is provided by the Subconsultant or is otherwise available, the Consultant must, in such reasonable time as not to delay or disrupt the carrying out of the Subcontract Services, give a decision on the required course of action.
Making of Decisions. If: the Consultant requests the Contractor to consider the selection of alternative courses of action; and all information required to enable a decision to be made is provided by the Consultant or is otherwise available, the Contractor must, in such reasonable time as not to delay or disrupt the carrying out of the Services, give a decision on the required course of action. Personnel
Making of Decisions. If: the Consultant requests the Commonwealth to consider the selection of alternative courses of action; and all information required to enable a decision to be made is provided by the Consultant or is otherwise available, the Commonwealth must, in such reasonable time as not to delay or disrupt the carrying out of the Services, give a decision on the required course of action.

Related to Making of Decisions

  • Notification of Decision The Committee shall consider a Claimant’s claim pursuant to Section 9.1 within a reasonable time, but no later than ninety (90) days after receiving the claim. If the Committee determines that special circumstances require an extension of time for processing the claim, written notice of the extension shall be furnished to the Claimant prior to the termination of the initial ninety (90) day period. In no event shall such extension exceed a period of ninety (90) days from the end of the initial period. The extension notice shall indicate the special circumstances requiring an extension of time and the date by which the Committee expects to render the benefit determination. The Committee shall notify the Claimant in writing:

  • Effect of Decision The decision or award of the arbitrator shall be final and binding upon the University, the UFF, and the grievant, provided that either party may appeal to an appropriate court of law a decision that was rendered by the arbitrator acting outside of or beyond the arbitrator's jurisdiction, pursuant to Section 682.13, Florida Statutes.

  • Credit Decisions Each Lender acknowledges that it has, independently of the Administrative Agent and each other Lender, and based on such Lender’s review of the financial information of the Borrower, the Loan Documents (the terms and provisions of which being satisfactory to such Lender) and such other documents, information and investigations as such Lender has deemed appropriate, made its own credit decision to extend its Commitments. Each Lender also acknowledges that it will, independently of the Administrative Agent and each other Lender, and based on such other documents, information and investigations as it shall deem appropriate at any time, continue to make its own credit decisions as to exercising or not exercising from time to time any rights and privileges available to it under the Loan Documents.

  • Review of Decision Within sixty (60) days after the Secretary’s receipt of a request for review, he or she will review the Company’s determination. After considering all materials presented by the Claimant, the Secretary will render a written opinion, written in a manner calculated to be understood by the Claimant, setting forth the specific reasons for the decision and containing specific references to the pertinent provisions of this Agreement on which the decision is based. If special circumstances require that the sixty (60) day time period be extended, the Secretary will so notify the Claimant and will render the decision as soon as possible, but no later than one hundred twenty (120) days after receipt of the request for review.

  • Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:

  • Finality of Decision The review by an ALJ or DAB provided for above shall not be considered to be an appeal right arising under any statutes or regulations. Consequently, the parties to this CIA agree that the DAB’s decision (or the ALJ’s decision if not appealed) shall be considered final for all purposes under this CIA.

  • Binding Effect of Decisions The decision or action of the Plan Administrator with respect to any question arising out of or in connection with the administration, interpretation and application of the Agreement and the rules and regulations promulgated hereunder shall be final and conclusive and binding upon all persons having any interest in the Agreement.

  • Making of Advances (i) In the event that Agent shall elect to have the terms of this Section 2.3(c) apply to a requested Borrowing as described in Section 2.3(b), then promptly after receipt of a request for a Borrowing pursuant to Section 2.3(a), Agent shall notify the Lenders, not later than 1:00 p.m. (California time) on the Business Day immediately preceding the Funding Date applicable thereto, by telecopy, telephone, or other similar form of transmission, of the requested Borrowing. Each Lender shall make the amount of such Lender’s Pro Rata Share of the requested Borrowing available to Agent in immediately available funds, to Agent’s Account, not later than 10:00 a.m. (California time) on the Funding Date applicable thereto. After Agent’s receipt of the proceeds of such Advances, upon satisfaction of the applicable conditions precedent set forth in Section 3 hereof, Agent shall make the proceeds thereof available to Administrative Borrower on the applicable Funding Date by transferring immediately available funds equal to such proceeds received by Agent to Administrative Borrower’s Designated Account; provided, however, that, subject to the provisions of Section 2.3(i), Agent shall not request any Lender to make, and no Lender shall have the obligation to make, any Advance if Agent shall have actual knowledge that (1) one or more of the applicable conditions precedent set forth in Section 3 will not be satisfied on the requested Funding Date for the applicable Borrowing unless such condition has been waived, or (2) the requested Borrowing would exceed the Availability on such Funding Date.

  • Final Decision Concessionaire covenants that the decision of the Commissioner of Department, relative to the performance of the terms and conditions of this Agreement, shall be final and conclusive.

  • Automated decisions For purposes hereof “automated decision” shall mean a decision by the data exporter or the data importer which produces legal effects concerning a data subject or significantly affects a data subject and which is based solely on automated processing of personal data intended to evaluate certain personal aspects relating to him, such as his performance at work, creditworthiness, reliability, conduct, etc. The data importer shall not make any automated decisions concerning data subjects, except when:

Time is Money Join Law Insider Premium to draft better contracts faster.