Maintaining the list Sample Clauses

Maintaining the list. It has been agreed that the Data Management team at CQC will maintain the list and keep it up-to-date. This will be done by the HTA providing CQC with information whenever a new organisation is licensed, or an existing licence is revoked, suspended or changed. That information will be provided by the central contact person in the HTA. The information supplied will include:  For new providers: the name of the service, contact details and licence details.  For revocations or suspensions of existing licences: details of the cancellation or suspension.  For changes to licences: details of amendments to the services’ licence including contact details, provider details or changes to the licence itself. When new information is received, CQC’s Data Management team will refresh the list and email an updated copy to the contact person in the HTA. Any changes that are made on the master list to CQC providers or to CQC compliance inspectors’ allocations will be automatically updated by CQC’s Data management team and included in their monthly refresh of the list. A routine updating and emailing of the list will be carried out by CQC in the first week of every month, where new information has been provided by the HTA or in the preceding month, or changes to CQC information have been made, so the list is continually up-to-date. The HTA should send any updated information for the master list to the CQC Data Management Team and copied to the CQC MoU manager:  CQC Data Management team: xxxxxxxxxxxxxx@xxx.xxx.xx  CQC MoU Manager: xxxxx.xxxxxxxx@xxx.xxx.xx Updated versions of the master list will be sent to:  CQC: xxxxx.xxxxxxxx@xxx.xxx.xx  HTA: xxxxxxx.xxxxxx@xxx.xxx.xx Any CQC compliance inspector who is affected by changes to the master list will also be notified.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Maintaining the list

  • Access to PHI Business Associate shall provide access to PHI in a Designated Record Set to Covered Entity or as directed by Covered Entity to an Individual to meet the requirements under 45 CFR § 164.524. Business Associate shall provide such access in the time and manner reasonably designated by Covered Entity. Within three (3) business days, Business Associate shall forward to Covered Entity for handling any request for access to PHI that Business Associate directly receives from an Individual.

  • Access to Personal Information by Subcontractors Supplier agrees to require any subcontractors or agents to which it discloses Personal Information under this Agreement or under any SOW to provide reasonable assurance, evidenced by written contract, that they will comply with the same or substantially similar confidentiality, privacy and security obligations with respect to such Personal Information as apply to Supplier under this Agreement or any SOW. Supplier shall confirm in writing to DXC that such contract is in place as a condition to DXC’s approval of use of a subcontractor in connection with any SOW. Upon request of DXC, Supplier will provide to DXC a copy of the subcontract or an extract of the relevant clauses. Supplier shall ensure that any failure on the part of any subcontractor or agent to comply with the Supplier obligations under this Agreement or any SOW shall be grounds to promptly terminate such subcontractor or agent. If during the term of this Agreement or any SOW, DXC determines, in its exclusive discretion, that any Supplier subcontractor or agent cannot comply with the Supplier obligations under this Agreement or with any SOW, then DXC may terminate this Agreement in whole or in part (with respect to any SOW for which such subcontractor or agent is providing services), if not cured by Supplier within the time prescribed in the notice of such deficiency.

  • Alignment with Modernization Foundational Programs and Foundational Capabilities The activities and services that the LPHA has agreed to deliver under this Program Element align with Foundational Programs and Foundational Capabilities and the public health accountability metrics (if applicable), as follows (see Oregon’s Public Health Modernization Manual, (xxxx://xxx.xxxxxx.xxx/oha/PH/ABOUT/TASKFORCE/Documents/public_health_modernization_man ual.pdf):

  • Access to Persons and Records The State Auditor shall have access to persons and records as a result of all contracts or grants entered into by State agencies or political subdivisions in accordance with General Statute 147-64.7. Additionally, as the State funding authority, the Department of Health and Human Services shall have access to persons and records as a result of all contracts or grants entered into by State agencies or political subdivisions.

  • Appointment of Key Sub-Contractors The Supplier shall ensure that all Sub-Contracts contain a provision: requiring the Supplier to pay any undisputed sums which are due from it to the Sub-Contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice; requiring that any invoices submitted by a Sub-Contractor shall be considered and verified by the Supplier in a timely fashion and that undue delay in doing so shall not be sufficient justification for failing to regard an invoice as valid and undisputed; requiring the Sub-Contractor to include in any Sub-Contract which it in turn awards suitable provisions to impose, as between the parties to that Sub-Contract, requirements to the same effect as those required by sub-clauses 5.17.1 and 5.17.2 directly above; and conferring a right to the Customer to publish the Supplier’s compliance with its obligation to pay undisputed invoices within the specified payment period. The Supplier shall pay any undisputed sums which are due from it to a Sub-Contractor within thirty (30) days from the receipt of a valid invoice. Any invoices submitted by a Sub-Contractor to the Supplier shall be considered and verified by the Supplier in a timely fashion. Undue delay in doing so shall not be sufficient justification for the Supplier failing to regard an invoice as valid and undisputed. Notwithstanding any provision of Clauses 9.2 (Confidentiality) and 13 (Publicity, Media and Official Enquiries) if the Supplier notifies the Customer that the Supplier has failed to pay an undisputed Sub-Contractor’s invoice within thirty (30) days of receipt, or the Customer otherwise discovers the same, the Customer shall be entitled to publish the details of the late or non-payment (including on Government websites and in the press).

  • Access to Books and Records Subject to Section 8.07, from the date hereof until the Closing Date, the Company shall provide the Purchaser and its authorized representatives (the “Purchaser’s Representatives”) and the Debt Financing Source Related Parties with reasonable access during normal business hours and upon reasonable notice to the offices, properties, senior personnel, books and records of the Company and its Subsidiaries in order for the Purchaser to have the opportunity to make such investigation as it shall reasonably desire of the affairs of the Company and its Subsidiaries; provided that, notwithstanding the foregoing, (a) such access does not unreasonably interfere with the normal operations of the Company or its Subsidiaries, (b) such access shall occur in such a manner as the Company reasonably determines to be appropriate to protect the confidentiality of the transactions contemplated by this Agreement, and (c) nothing herein shall require the Company to provide access to, or to disclose any information to, the Purchaser or any of the Purchaser’s Representatives if such access or disclosure would reasonably be expected to (i) cause significant competitive harm to the Company or its Subsidiaries if the transactions contemplated by this Agreement are not consummated, (ii) waive any legal privilege, or (iii) be in violation of applicable Law (including the HSR Act and other antitrust Laws). The Purchaser acknowledges that the Purchaser is and remains bound by that certain Confidentiality Agreement, dated as of April 21, 2015 (as amended from time to time, the “Confidentiality Agreement”), by and between Purchaser and GTCR LLC (“GTCR”). The information provided pursuant to this Section 7.02 will be used solely for the purpose of effecting the transactions contemplated by this Agreement, and will be governed by all the terms and conditions of the Confidentiality Agreement.

  • Extent of Cooperation (1) Prior to December 31, 2017, Counsel for the Settling Defendants met with Class Counsel in Canada or the United States, to provide an oral evidentiary proffer which included information originating with the Settling Defendants that was not covered by privilege relating to the allegations in the Proceedings. Notwithstanding any other provision of this Settlement Agreement, and for greater certainty, it is agreed that all statements made and information provided by Counsel for the Settling Defendants are privileged, will be kept strictly confidential, may not be directly or indirectly disclosed to any other Person, unless disclosure is ordered by a Court. Further, absent a Court order, Class Counsel will not attribute any factual information obtained from the proffer to the Settling Defendants and/or Counsel for the Settling Defendants. Notwithstanding the foregoing, Class Counsel may: (i) use information obtained from the proffer in the prosecution of the Proceedings, including for the purpose of developing an allocation plan relating to any settlement or judgment proceeds, except the prosecution of any claims against Releasees; and (ii) may rely on such information to certify that, to the best of Class Counsel’s knowledge, information and belief, such information has evidentiary support or will likely have evidentiary support after reasonable opportunity for further investigation or discovery, but, absent a Court Order, the Plaintiffs shall not introduce any information from a proffer into the record or subpoena any Counsel for the Settling Defendants related to a proffer.

  • Access to NID 2.17.3.1 TWTC may access the customer’s premises wiring by any of the following means and TWTC shall not disturb the existing form of electrical protection and shall maintain the physical integrity of the NID:

  • Access to Personnel File Each employee shall have reasonable access to his/her personnel file for the purpose of reviewing any evaluations or formal disciplinary notations contained therein, in the presence of the Director of Personnel or designate. An employee has the right to request copies of any evaluations in this file.

  • Areas of Cooperation The Parties will cooperate, in particular, in the following areas of common interest:

Time is Money Join Law Insider Premium to draft better contracts faster.