Tenant Estoppel If a Tenant Estoppel is delivered by Sellers to Buyer, Buyer may nevertheless disapprove such Tenant Estoppel if and only if it does not contain such items as are required to be given in connection with an estoppel certificate pursuant to the Tenant’s Lease, or contains allegations of an uncured material default by a Seller or contains information that materially deviates from the facts and financial information contained in the Offering Memorandum, the Due Diligence Materials or in this Agreement. If Sellers are unable to obtain Tenant Estoppels from a sufficient number of Tenants to satisfy the ********** ******* (***) *********** set forth in this Section 7.2(b) on or before the Closing Date (or have not delivered Tenant Estoppels from the Required Tenants), then the Closing Date for any applicable Portfolio shall be adjourned for a period not to exceed thirty (30) days for Sellers to obtain the sufficient number of Tenant Estoppels (or Estoppel Certificates from the Required Tenants, as the case may be). In addition, if Sellers are unable to obtain Tenant Estoppels from a sufficient number of Tenants to satisfy the ********** ******* (***) *********** set forth in this Section 7.2(b) on or before the Closing Date (as may be extended hereunder), an individual Seller shall have the right to elect to execute and deliver to Buyer a certificate substantially in the form of Exhibit P attached hereto (each such certificate, a “Seller’s Estoppel”) with respect to such additional lease(s) at such individual Seller’s Building and selected by Seller as would satisfy the requirement; provided, however, that an individual Seller shall not have the right to deliver a Seller’s Estoppel in lieu of Tenant Estoppels from Required Tenants. In the event that an individual Seller elects to deliver such a Seller’s Estoppel, each statement therein made by such Seller shall constitute warranties and representations by such Seller hereunder which shall survive for a period terminating on the earlier of (i) December 28, 2006, or (ii) the date on which Buyer has received an executed Tenant Estoppel signed by the applicable Tenant under the Lease in question that is not inconsistent with Seller’s Estoppel. With respect to the rentable area of the Buildings leased to the GSA, each individual Seller shall, as applicable, use commercially reasonable efforts to obtain a supplemental lease agreement, novation agreement, statement of lease or similar instrument delivered by the GSA (a “GSA Estoppel”) for Leases to the GSA in excess of 10,000 rentable square feet (a “Material GSA Lease”); provided, however, the delivery of a GSA Estoppel shall not be a condition precedent to Buyer’s obligation to consummate the transaction contemplated hereunder; provided, further that Sellers shall execute and deliver to Buyer a certificate substantially in the form of Exhibit P attached hereto (each such certificate, a “Seller’s GSA Estoppel”) with respect to all Material GSA Leases at such individual Seller’s Building. In the event that an individual Seller elects to deliver such a Seller’s GSA Estoppel, each statement therein made by such Seller shall constitute warranties and representations by such Seller hereunder which shall survive for a period terminating on the earlier of (i) December 28, 2006, or (ii) the date on which Buyer has received an executed GSA Estoppel signed by the GSA under the Material GSA Lease in question.
Tenant Estoppels (a) Each Seller shall prepare and deliver to each Tenant at such Seller’s Property an estoppel certificate in the form of Exhibit A attached hereto (the “Tenant Estoppel”) and request each such Tenant to execute and deliver the Tenant Estoppel to such Seller. Each Seller shall use commercially reasonable efforts to obtain the prompt return of the executed Tenant Estoppels in substantially the same form as Exhibit A attached hereto from each Tenant at such Seller’s Property prior to the Closing, without the obligation to make any payments or grant any concessions under the Leases. If a Tenant returns an executed Tenant Estoppel (or Lease Required Estoppel or Statement of Lease as defined below) to such Seller, such Seller shall promptly deliver to the Buyer, or make available on Seller’s transaction website, a copy of such executed Tenant Estoppel (or Lease Required Estoppel or Statement of Lease, if applicable) following such Seller’s receipt of such Tenant Estoppel (or Lease Required Estoppel or Statement of Lease, if applicable).
Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Regulatory Approvals; No Defaults (a) No consents or approvals of, or waivers by, or filings or registrations with, any Governmental Authority are required to be made or obtained by HCBF or any of its Subsidiaries in connection with the execution, delivery or performance by HCBF of this Agreement or to consummate the transactions contemplated by this Agreement, except as may be required for (i) filings of applications and notices with, and receipt of consents, authorizations, approvals, exemptions or nonobjections from, the SEC, NASDAQ, state securities authorities, the Financial Industry Regulatory Authority, Inc., applicable securities, commodities and futures exchanges, and other industry self-regulatory organizations (each, an “SRO”), (ii) filings of applications or notices with, and consents, approvals or waivers by the FRB, the FDIC and applicable state banking agencies, the Office of the Comptroller of the Currency (the “OCC”), the Florida Office of Financial Regulation (the “FOFR”) and other banking, regulatory, self-regulatory or enforcement authorities or any courts, administrative agencies or commissions or other Governmental Authorities and approval of or non-objection to such applications, filings and notices (taken together with the items listed in clause (i), the “Regulatory Approvals”), (iii) the filing with the SEC of the Proxy Statement-Prospectus and the Registration Statement and declaration of effectiveness of the Registration Statement, (iv) the filing of the Articles of Merger and the filing of documents with the OCC, applicable Governmental Authorities, and the Secretary of State of the State of Florida to cause the Bank Merger to become effective and (v) such filings and approvals as are required to be made or obtained under the securities or “Blue Sky” laws of various states in connection with the issuance of the shares of CenterState Common Stock pursuant to this Agreement and approval of listing of such CenterState Common Stock on the NASDAQ. Subject to the receipt of the approvals referred to in the preceding sentence and the Requisite HCBF Shareholder Approval, the execution, delivery and performance of this Agreement and the consummation of the transactions contemplated hereby by HCBF do not and will not (1) constitute a breach or violation of, or a default under, the articles of incorporation, bylaws or similar governing documents of HCBF or any of its respective Subsidiaries, (2) violate any statute, code, ordinance, rule, regulation, judgment, order, writ, decree or injunction applicable to HCBF or any of its Subsidiaries, or any of their respective properties or assets, (3) conflict with, result in a breach or violation of any provision of, or the loss of any benefit under, or a default (or an event which, with or without notice or lapse of time, or both, would constitute a default) under, result in the creation of any Lien under, result in a right of termination or the acceleration of any right or obligation under any permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, contract, franchise, agreement or other instrument or obligation of HCBF or any of its Subsidiaries or to which HCBF or any of its Subsidiaries, or their respective properties or assets is subject or bound, or (4) require the consent or approval of any third party or Governmental Authority under any such Law, rule or regulation or any judgment, decree, order, permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, contract, franchise, agreement or other instrument or obligation.
Landlord Consent Notwithstanding anything to the contrary herein, this Assignment shall not be effective until Landlord has signed and delivered to Assignor and Assignee Landlord’s written consent to this Assignment (the “Consent”) pursuant to a consent in form and content mutually agreeable to Landlord, Assignor and Assignee, which form and content shall be deemed to be mutually agreeable upon Landlord’s, Assignor’s and Assignee’s execution and delivery of the Consent. In the event, for any reason whatsoever, the Consent is not delivered by Landlord within thirty (30) days after the execution of this Assignment by Assignor and Assignee, Assignor and Assignee each shall have the right, in its sole and absolute discretion, until such time as Landlord delivers the Consent, to terminate this Assignment by providing written notice to the other, in which case this Assignment shall automatically terminate and neither party shall owe any obligation to the other party. For avoidance of doubt, unless waived by Assignor and Assignee by their execution and delivery of the Consent, the Consent shall not be deemed given unless Landlord agrees, amongst other terms and conditions that (i) Landlord consents to the reduction of the Security Deposit; (ii) Landlord consents to the assignment of the right to exercise the Extension Right; (iii) Landlord agrees that Assignor shall be released from all liability and obligations under the Lease during the Extension Term; (iv) Landlord confirms and agrees in the Consent that neither Assignor nor Assignee shall be required to remove any improvements present as of the Effective Date; and (v) Landlord consents to the prepayment of the outstanding principal balance of the Remaining TI Rent.
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Certificate of Occupancy; Licenses All certifications, permits, franchises, licenses, consents, authorizations, and approvals, including, certificates of completion and occupancy permits, required for the legal use, occupancy and operation of the Property have been obtained and are in full force and effect. The use being made of the Property is in conformity with the certificate of occupancy issued for the Property.
Property Insurance Building Improvements and Rental Value 9.2.1 Lessor shall obtain and keep in force a policy or policies of insurance in the name of Lessor, with loss payable to Lessor, any ground-lessor, and to any Lender insuring loss or damage to the Premises. The amount of such insurance shall be equal to the full insurable replacement cost of the Premises, as the same shall exist from time to time, or the amount required by any Lender, but in no event more than the commercially reasonable and available insurable value thereof. If the coverage is available and commercially appropriate, such policy or policies shall insure against all types of direct physical loss or damage (except the perils of flood and/or earthquake unless required by a Lender), including coverage for debris removal and the enforcement of any Applicable Requirements requiring the upgrading, demolition, reconstruction or replacement of any portion of the Premises as the result of a covered loss. Said policy or policies shall also contain an agreed valuation provision in lieu of any coinsurance clause, waiver of subrogation, and inflation guard protection causing an increase in the annual property insurance coverage amount by a factor of not less than the adjusted U.S. Department of Labor Consumer Price Index for All Urban Consumers for the city nearest to where the Premises are located. Lessee Owned Alterations and Utility Installations, Trade Fixtures, and Lessee’s personal property shall be insured by Lessee not by Lessor unless the item in question has become the property of Lessor under the terms of this Lease.
