Late Completion Notification Sample Clauses
The Late Completion Notification clause requires one party, typically the contractor or service provider, to formally inform the other party if a project or deliverable will not be completed by the agreed deadline. This notification usually includes details about the expected delay, reasons for the late completion, and a revised timeline for delivery. By mandating prompt communication of delays, the clause helps manage expectations, allows for contingency planning, and reduces the risk of disputes arising from missed deadlines.
POPULAR SAMPLE Copied 1 times
Late Completion Notification. If at any time, the updated Critical Path of the Performance Schedule indicates a late delivery or late completion date, the Buyer shall notify the Contracting Officer and the COTR in writing the next working day, and/or prior to the beginning of any period when no work will occur, such as a holiday period. This notification shall include identification of the problem and shall propose corrective actions for schedule recovery. NOTE: The buyer’s inclusion of various schedule impacts in its Performance Schedule does not change the Contract Period of Performance in ARTICLE V unless the Contracting Officer authorizes an extension under ARTICLE XVII.