Landlord's Waiver Prior to the Bank making the first Revolving Loan, the Borrower will obtain, and will thereafter maintain in effect at all times, waivers from the owners of all premises in which any material amount of Collateral is located, such waivers to be in form and substance satisfactory to the Bank.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Release of Landlord If, during the term of this Lease, Landlord shall sell its interest in the Building or Complex of which the Leased Premises form a part, or the Leased Premises, then from and after the effective date of the sale or conveyance, Landlord shall be released and discharged from any and all obligations and responsibilities under this Lease, except those already accrued.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Landlord’s Election If Tenant desires to assign its interest under the Lease or to sublet all or part of the Leased Premises (a “Proposed Transfer”), Tenant must first notify Landlord, in writing, of such Proposed Transfer, at least fifteen (15) business days in advance of the date it intends to close the Proposed Transfer, specifying (a) the size of the space to be so transferred, (b) the duration of the term of such Proposed Transfer and (c) the terms of the Proposed Transfer, including the name of the proposed assignee or sublessee, the proposed assignee’s or sublessee’s intended use of the Leased Premises, current financial statements (including a balance sheet, income statement and statement of cash flow, all prepared in accordance with generally accepted accounting principles) of such proposed assignee or sublessee, the form of documents to be used in effectuating such assignment or subletting and such other information as Landlord may reasonably request. Landlord shall have a period of fifteen (15) business days following receipt of such notice and the required information to consent or decline to consent to the Proposed Transfer. If Landlord does not respond within such fifteen (15) business day period, Landlord shall be deemed to have approved the Proposed Transfer. If Landlord declines to consent to the Proposed Transfer, Landlord shall notify Tenant in writing, specifying the reasons under this Lease that such refusal is justified. During such fifteen (15) business day period, Tenant covenants and agrees to supply to Landlord, promptly upon request, all necessary or relevant information which Landlord may reasonably request respecting such proposed assignment or subletting and/or the proposed assignee or sublessee.
Landlord's Improvements All fixtures, improvements or equipment which are installed, constructed on or attached to the Premises or Common Area by Landlord shall be a part of the realty and belong to Landlord.
