Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
BACKGROUND INVESTIGATION The BOARD is prohibited from knowingly employing a person who has been convicted of committing or attempting to commit certain criminal offenses. If the required criminal background investigation is not completed at the time this Contract is signed, and the subsequent investigation report reveals that there has been a prohibited conviction, this Contract shall immediately become null and void.
No Hazardous Materials (A) have been disposed of or otherwise released from any Real Property of the Company or any of its Subsidiaries in violation of any Environmental Laws; or
DISCOVERY OF HAZARDOUS MATERIALS If, during the performance of the Work, Contractor or Contractor’s subcontractor(s) encounter material believed to be asbestos, polychlorinated biphenyl (PCB), or any other identified or non-identified potentially hazardous material (which has not been rendered harmless and labeled as such), Contractor and Contractor’s subcontractor(s) shall immediately stop work in the area affected and report the condition, in writing, to District. The Work in the affected area shall not continue or be resumed except by written direction of District and by agreement by Contractor.
Prohibition Against Selecting and Installing Products Containing Hazardous Materials The Contractor shall not select, install or otherwise incorporate any products or materials containing Hazardous Materials within the boundaries of the Site. Should the Contractor or any Subcontractors have knowledge that, or believe that, an item, component, material, substance, or accessory within a product or assembly selected by the Contractor or any Subcontractor may contain Hazardous Materials it is the Contractor’s responsibility to secure a written certification from the manufacturer of any suspected material which identifies the specific Hazardous Material(s) contained, together with the Material Safety Data Sheets (MSDS) for such materials which shall be submitted to the Owner and Design Professional.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
Background Investigations OSC policy requires that background investigations be conducted on Contractor Staff who will have access to OSC’s IT systems, access to OSC confidential information/data, or routine access to any OSC facility. For purposes of this policy, “routine access” is defined as access to an OSC facility for five consecutive business days or 10 business days over the annual term of the engagement. Accordingly, with the signing of this Agreement, the Contractor certifies that it has or will conduct a background investigation on Staff to whom the policy applies within the 12 months prior to the Staff commencing Services under this Agreement. The Contractor agrees to undertake a background investigation of any new/replacement Staff during the term of the Agreement. At a minimum, background investigations shall include a review/evaluation of the following: • identity verification, including Social Security Number search; • employment eligibility, including verification of U.S. citizenship or legal immigration status where appropriate; • criminal history/court records (Federal, State and local for the past five years); • work experience/history for the past five years; • pertinent skills, qualifications, and education/professional credentials; and • references. The Contractor must obtain the consent of its Staff to allow OSC, upon request: (i) to review the background investigation records, including all supporting documentation, and (ii) to conduct its own background investigation. Only Staff who have passed the background investigation, and provided such consent shall be assigned to provide Services to OSC under this Agreement. During the term of the Agreement, and in accordance with Appendix A (Section 10, Records), the Contractor must maintain records related to the background investigations performed.
REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.
Criminal Background Investigations For investigative Vendor Staff, Citizens will accept a copy of a current Class C Private Investigator license as proof that a criminal background check has been conducted for that investigator. For all other Vendor Staff, Vendor must provide Citizens with a copy of a criminal background check performed on such Vendor Staff dated within thirty (30) days of submission of the Vendor Staff to Citizens for qualification and credentialing review. Vendor shall use Exhibit D, Applicant Background Review Guide to as a guideline to determine eligibility of Vendor Staff to perform Services. The criminal background check must be updated every two (2) years thereafter. All background checks will be at Vendor’s expense and, unless otherwise approved in writing by Citizens’ Contract Manager, shall include but not be limited to: (a) state and federal felony convictions or pending adjudications; (b) state and federal misdemeanor convictions or pending adjudications; (c) any crimes in violation of the Violent Crime Control and Law Enforcement Act of 1995 or pending adjudications; and, (d) a seven (7) year minimum timeframe, extending as close as practicable to the date of Assignment to perform Services. Vendor will advise Citizens’ Contract Manager or designee if it knows of any Vendor Staff that has a criminal conviction (misdemeanor or felony), regardless of adjudication (adjudication withheld, a plea of guilty or nolo contendere, or a guilty verdict), within the last ten (10) years in any jurisdiction. Vendor shall not allow that individual to act as a Vendor Staff until Vendor determines whether that individual should be allowed to do so considering (a) the nature and gravity of the offense; (b) the amount of time that lapsed since the offense;
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
