Delivery and Risk of Loss Unless otherwise provided for in advance, all shipments will be made F.O.B. Seller's facility, and upon Seller's delivery of a shipment to the carrier, Buyer shall assume the risk of any loss or damage to the shipment thereafter. Delivery and/or completion dates furnished by Seller represent the best estimates of the time required to make shipment or complete services, and Seller does not guarantee delivery or completion by a particular date unless otherwise stated herein or in any schedule or addendum attached hereto. If a delivery date for products is guaranteed herein, (a) Seller’s unexcused delay in delivering one installment to the carrier at Seller’s facility shall permit Buyer to cancel only that installment, and acceptance by Buyer or the act of taking possession of products by the carrier shall constitute a bar to any claim of late delivery with respect to such products and (b) Buyer shall not be excused from performance if for any reason, the carrier does not pick up products on the date specified for shipping, and Seller may dispose of any products which the carrier does not pick-up within five (5) days of the date agreed for delivery to the carrier at Seller’s facility if Buyer refuses acceptance based on such delay, in which case Seller may cancel the order without notice to Buyer and Buyer shall be responsible for a 25% restocking fee as to the products ordered. In any such event, Seller shall have no duty to mitigate its damages. Seller may deliver any products subject to an order to the carrier at its facility in part and in such event, Buyer shall be responsible for payment for that part of the order received by the carrier, and Seller shall only be responsible for that portion of an order which Seller is required to but does not deliver. Unless otherwise required by a contract of Buyer with a customer of Buyer with respect only to products ordered by such customer, Title shall not pass with respect to any products ordered until Buyer makes payment in full thereof. In the alternative, Seller reserves a purchase money security interest in the products sold as well as any other products or property forwarded to Seller by Buyer for servicing or evaluation until full payment has been received. Buyer agrees to execute any document appropriate or necessary to perfect Seller's security interest or to acknowledge that title remains with Seller. In the alternative, Seller may file this order as a financing statement and/or chattel mortgage. Buyer agrees that, upon its failure to pay any invoice when due, Seller may immediately foreclose upon and sell, in a manner determined by Seller, any products or property owned by or provided by Buyer to Seller, regardless of whether such products or property are the subject of the unpaid invoice, in order to allow Seller to recover all amounts, including but not limited to interest and penalties, owed by Buyer to Seller.
Delivery and Documents 13.1 Subject to GCC Sub-Clause 33.1, the delivery of the Goods and completion of the Related Services shall be in accordance with the List of Goods and Delivery Schedule specified in the Supply Requirements. The details of shipping and other documents to be furnished by the Supplier are specified in the SCC.
Delivery and Risk 7.1 Unless otherwise stated in the Order, the price quoted includes delivery to the address specified in the Order.
NOTIFICATION OF PUBLIC EVENTS AND MEETINGS 2 A. CONTRACTOR shall notify ADMINISTRATOR of any public event or meeting funded in 3 whole or in part by the COUNTY, except for those events or meetings that are intended solely to serve 4 clients or occur in the normal course of business.
COMPLIANCE WITH BREACH NOTIFICATION AND DATA SECURITY LAWS Contractor shall comply with the provisions of the New York State Information Security Breach and Notification Act (General Business Law § 899-aa and State Technology Law § 208) and commencing March 21, 2020 shall also comply with General Business Law § 899-bb.
NON-DELIVERY OF POSSESSION In the event Landlord cannot deliver possession of the Premises to Tenant upon the commencement of the Lease term, through no fault of Landlord or its agents, then Landlord or its agents shall have no liability, but the rental herein provided shall xxxxx until possession is given. Landlord or its agents shall have thirty (30) days in which to give possession, and if possession is tendered within such time, Tenant agrees to accept the demised Premises and pay the rental herein provided from that date. In the event possession cannot be delivered within such time, through no fault of Landlord or its agents, then this Agreement and all rights hereunder shall terminate.
Filling of Positions All eligible employees under Section 3 who have made a timely interest bid, and meet the minimum qualifications, shall be given consideration and may be appointed to the opening prior to the consideration of other non-interest bidding applicants and prior to filling the vacancy through other means. The Appointing Authority shall not be arbitrary, capricious, or discriminatory and must have a legitimate business reason to reject all of the interest bidders. Seniority of the interest bidders shall not be a factor in appointing employees from among the interest bidders. All interest bidders shall be notified orally or in writing, which may include electronic mailing, as to the status (either under consideration, acceptance, or rejection) of their interest bid in a timely manner. If the vacancy is not filled by an employee under this Section, then it shall be filled in the following order:
Delivery of Possession Landlord shall be deemed to have delivered possession of the Premises to Tenant on the Commencement Date, as it may be adjusted pursuant to the Workletter. Landlord shall construct or install in the Premises the improvements to be constructed or installed by Landlord according to the Workletter. If no Workletter is attached to this Lease, it shall be deemed that Landlord delivered to Tenant possession of the Premises "as is" in its present condition on the Commencement Date. Tenant acknowledges that neither Landlord nor its agents or employees have made any representations or warranties as to the suitability or fitness of the Premises for the conduct of Tenant's business or for any other purpose, nor has Landlord or its agents or employees agreed to undertake any alterations or construct any Tenant improvements to the Premises except as expressly provided in this Lease and the Workletter. If for any reason Landlord cannot deliver possession of the Premises to Tenant on the Commencement Date, this Lease will not be void or voidable, Landlord will not be liable to Tenant for any resulting loss or damage and the Term of this Lease shall not be extended by a delayed delivery of possession. The preceding sentence notwithstanding, if Landlord fails to deliver possession to Tenant within sixty (60) days after the Commencement Date for any reason other than a Delay Caused by Tenant, as defined in the Workletter, Tenant, as its sole remedy, shall have the right to terminate this Lease and receive a refund of all prepaid Rent and Security Deposits provided Tenant gives written notice of termination to Landlord within three (3) days after that date. Tenant will execute the Commencement Date Certificate attached to this Lease as Exhibit E, appropriately completed, within fifteen (15) days of Landlord's request.
DELIVERY AND TITLE 3.1 The delivery dates and addresses are those in the Order. Time shall be of the essence in respect of the Supplier/Service Provider’s obligations under the Order.
Introduction and Statement of Policy The National Institutes of Health (NIH) has established NIH-designated data repositories (e.g., database of Genotypes and Phenotypes (dbGaP), Sequence Read Archive (SRA), NIH Established Trusted Partnerships) for securely storing and sharing controlled-access human data submitted to NIH under the NIH Genomic Data Sharing (GDS)
