Additional Requirements for All Policies All policies shall be endorsed to provide at least thirty (30) days' advance written notice to City of cancellation of policy for any reason, nonrenewal or reduction in coverage and specific notice mailed to City's address for notices pursuant to Article 15.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Additional Requirements As a condition precedent to the execution and Delivery, the registration of issuance, transfer, split-up, combination or surrender, of any ADS, the delivery of any distribution thereon, or the withdrawal of any Deposited Property, the Depositary or the Custodian may require (i) payment from the depositor of Shares or presenter of ADSs or of an ADR of a sum sufficient to reimburse it for any tax or other governmental charge and any stock transfer or registration fee with respect thereto (including any such tax or charge and fee with respect to Shares being deposited or withdrawn) and payment of any applicable fees and charges of the Depositary as provided in Section 5.9 and Exhibit B, (ii) the production of proof reasonably satisfactory to it as to the identity and genuineness of any signature or any other matter contemplated by Section 3.1, and (iii) compliance with (A) any laws or governmental regulations relating to the execution and Delivery of ADRs or ADSs or to the withdrawal of Deposited Securities and (B) such reasonable regulations as the Depositary and the Company may establish consistent with the provisions of the representative ADR, if applicable, the Deposit Agreement and applicable law.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
SPECIAL CONTRACT REQUIREMENTS The Special Contract Requirements are provisions that relate directly to the performance of this contract.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
General Requirements for Insurance Coverage and Policies A. All required insurance policies shall be maintained with companies that may lawfully issue the required policy and have an A.M. Best rating of at least A- / “VII” or a Standard and Poor’s rating of at least A, unless prior written approval is obtained from the City Law Department.
