Delivery of Possession Landlord shall be deemed to have delivered possession of the Premises to Tenant on the Commencement Date, as it may be adjusted pursuant to the Workletter. Landlord shall construct or install in the Premises the improvements to be constructed or installed by Landlord according to the Workletter. If no Workletter is attached to this Lease, it shall be deemed that Landlord delivered to Tenant possession of the Premises "as is" in its present condition on the Commencement Date. Tenant acknowledges that neither Landlord nor its agents or employees have made any representations or warranties as to the suitability or fitness of the Premises for the conduct of Tenant's business or for any other purpose, nor has Landlord or its agents or employees agreed to undertake any alterations or construct any Tenant improvements to the Premises except as expressly provided in this Lease and the Workletter. If for any reason Landlord cannot deliver possession of the Premises to Tenant on the Commencement Date, this Lease will not be void or voidable, Landlord will not be liable to Tenant for any resulting loss or damage and the Term of this Lease shall not be extended by a delayed delivery of possession. The preceding sentence notwithstanding, if Landlord fails to deliver possession to Tenant within sixty (60) days after the Commencement Date for any reason other than a Delay Caused by Tenant, as defined in the Workletter, Tenant, as its sole remedy, shall have the right to terminate this Lease and receive a refund of all prepaid Rent and Security Deposits provided Tenant gives written notice of termination to Landlord within three (3) days after that date. Tenant will execute the Commencement Date Certificate attached to this Lease as Exhibit E, appropriately completed, within fifteen (15) days of Landlord's request.
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
Tender of Possession Landlord and Tenant presently anticipate that possession of the Premises will be tendered to Tenant in the condition required by this Lease on or about February 1, 2013 or, if later, 65 days following Tenant’s execution and delivery of this Lease to Landlord, regardless of the date on which Landlord countersigns this Lease (such later date being the “Estimated Delivery Date”). If Landlord does not tender possession of the Premises with the Work Substantially Completed to Tenant by the Estimated Delivery Date, then (a) the validity of this Lease shall not be affected or impaired thereby, (b) Landlord shall not be in default hereunder or be liable for damages therefor, and (c) Tenant shall accept possession of the Premises when Landlord tenders possession thereof to Tenant. Tenant shall have early access to the Premises as provided in Section 26.2. By occupying the Premises, Tenant shall be deemed to have accepted the Premises in their condition as of the date of such occupancy, subject to the performance of punch-list items that remain to be performed by Landlord, if any. Prior to occupying the Premises, Tenant shall execute and deliver to Landlord a letter substantially in the form of Exhibit E hereto confirming (1) the Commencement Date and the expiration date of the initial Term, (2) that Tenant has accepted the Premises, and (3) that Landlord has performed all of its obligations with respect to the Premises (except for punch-list items specified in such letter); however, the failure of the parties to execute such letter shall not defer the Commencement Date or otherwise invalidate this Lease. Entry into the Premises by any Tenant Party prior to the Commencement Date shall be subject to all of the provisions of this Lease excepting only those requiring the payment of Basic Rent and Additional Rent.
Delivery of the Property The Fund will deliver or arrange for delivery to PFPC Trust, all the Property owned by the Portfolios, including cash received as a result of the distribution of Shares, during the term of this Agreement. PFPC Trust will not be responsible for any assets until actual receipt.
Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.
Operation of the Property During the Term, NAI shall operate the Property in a good and workmanlike manner and substantially in compliance with all Applicable Laws and will pay or cause to be paid all fees or charges of any kind in connection therewith. (If NAI does not promptly correct any failure of the Property to comply with Applicable Laws that is the subject of a written notice given to NAI or BNPLC by any governmental authority, then for purposes of the preceding sentence, NAI shall be considered not to have maintained the Property "substantially in accordance with Applicable Laws" whether or not the noncompliance would be substantial in the absence of the notice.) During the Term, NAI shall not use or occupy, or allow the use or occupancy of, the Property in any manner which violates any Applicable Law or which constitutes a public or private nuisance or which makes void, voidable or cancelable any insurance then in force with respect thereto. During the Term, to the extent that any of the following would, individually or in the aggregate, materially and adversely affect the value of the Property or NAI's use, occupancy or operations on the Property, NAI shall not, without BNPLC's prior consent: (i) initiate or permit any zoning reclassification of the Property; (ii) seek any variance under existing zoning ordinances applicable to the Property; (iii) use or permit the use of the Property in a manner that would result in such use becoming a nonconforming use under applicable zoning ordinances or similar laws, rules or regulations; (iv) execute or file any subdivision plat affecting the Property; or (v) consent to the annexation of the Property to any municipality. If (A) a change in the zoning or other Applicable Laws affecting the permitted use or development of the Property shall occur after the Base Rent Commencement Date that reduces the value of the Property, or (B) conditions or circumstances on or about the Property are discovered after the Base Rent Commencement Date (such as the presence of an endangered species) which substantially impede development and thereby reduce the value of the Property, and if after any such reduction under clause (A) or (B) preceding the Current AS IS Market Value of the Property is less than sixty percent (60%) of Stipulated Loss Value, then NAI shall pay BNPLC upon request the amount by which Current AS IS Market Value is less than sixty percent (60%) of Stipulated Loss Value, for application as a Qualified Prepayment. During the Term, NAI shall not cause or permit any drilling or exploration for, or extraction, removal or production of, minerals from the surface or subsurface of the Property, and NAI shall not do any act whereby the market value of the Property may reasonably be expected to be materially lessened. During the Term, if NAI receives a written notice or claim from any federal, state or other governmental entity that the Property is not in compliance in any material respect with any Applicable Law, or that any action may be taken against the owner of the Property because the Property does not comply with Applicable Law, NAI shall promptly furnish a copy of such notice or claim to BNPLC. Notwithstanding the foregoing, NAI may in good faith, by appropriate proceedings, contest the validity and applicability of any Applicable Law with respect to the Property, and pending such contest NAI shall not be deemed in default hereunder because of the violation of such Applicable Law, if NAI diligently prosecutes such contest to completion in a manner reasonably satisfactory to BNPLC, and if NAI promptly causes the Property to comply with any such Applicable Law upon a final determination by a court of competent jurisdiction that the same is valid and applicable to the Property; provided, however, in any event such contest shall be concluded and the violation of such Applicable Law must be corrected by NAI and any claims asserted against BNPLC or the Property because of such violation must be paid by NAI, all prior to the earlier of (i) the date that any criminal prosecution is instituted or overtly threatened against BNPLC or any of its directors, officers or employees because of such violation, (ii) the date that any action is taken by any governmental authority against BNPLC or any property owned by BNPLC (including the Property) because of such violation, or (iii) a Designated Sale Date upon which, for any reason, NAI or an Affiliate of NAI or any Applicable Purchaser shall not purchase BNPLC's interest in the Property pursuant to the Purchase Agreement for a price to BNPLC (when taken together with any additional payments made by NAI pursuant to Paragraph 1(A)(2) of the Purchase Agreement, in the case of a purchase by an Applicable Purchaser) equal to the Break Even Price.
Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.
Termination of Possession Terminate Tenant’s right to possess the Premises without terminating this Lease by giving written notice thereof to Tenant, in which event Tenant shall pay to Landlord (a) all Rent and other amounts accrued hereunder to the date of termination of possession, (b) all amounts due from time to time under Section 19.1, and (c) all Rent and other net sums required hereunder to be paid by Tenant during the remainder of the Term, diminished by any net sums thereafter received by Landlord through reletting the Premises during such period, after deducting all costs incurred by Landlord in reletting the Premises. If Landlord elects to terminate Tenant’s right to possession without terminating this Lease, and to retake possession of the Premises (and Landlord shall have no duty to make such election), Landlord shall use reasonable efforts to relet the Premises as further described in Section 19.4 below. Provided Landlord substantially complies with Section 19.4, Landlord shall not be liable for, nor shall Tenant’s obligations hereunder be diminished because of, Landlord’s failure to relet the Premises or to collect rent due for such reletting. Tenant shall not be entitled to the excess of any consideration obtained by reletting over the Rent due hereunder. Reentry by Landlord in the Premises shall not affect Tenant’s obligations hereunder for the unexpired Term; rather, Landlord may, from time to time, bring an action against Tenant to collect amounts due by Tenant, without the necessity of Landlord’s waiting until the expiration of the Term. Unless Landlord delivers written notice to Tenant expressly stating that it has elected to terminate this Lease, all actions taken by Landlord to dispossess or exclude Tenant from the Premises shall be deemed to be taken under this Section 18.2. If Landlord elects to proceed under this Section 18.2, it may at any time elect to terminate this Lease under Section 18.1;
Surrender of Possession Immediately prior to the expiration or upon the sooner termination of this Lease, Tenant shall remove all of Tenant’s signs from the exterior of the Building and shall remove all of Tenant’s equipment, trade fixtures, furniture, supplies, wall decorations and other personal property from the Leased Premises, and shall vacate and surrender the Leased Premises to Landlord in the same condition, broom clean, as existed at the Lease Commencement Date. Tenant shall repair all damage to the Leased Premises caused by Tenant or by Tenant’s removal of Tenant’s property and all damage to the exterior of the Building caused by Tenant’s removal of Tenant’s signs. Tenant shall patch and refinish, to Landlord’s reasonable satisfaction, all penetrations made by Tenant or its employees to the floor, walls or ceiling of the Leased Premises, whether such penetrations were made with Landlord’s approval or not. Tenant shall clean, repair or replace all stained or damaged ceiling tiles, wall coverings and clean or replace as may be required floor coverings to the reasonable satisfaction of Landlord. Tenant shall replace all burned out light bulbs and damaged light lenses, and clean and repaint all painted walls. Tenant shall repair all damage caused by Tenant to the exterior surface of the Building and the paved surfaces of the outside areas adjoining the Leased Premises and, where necessary, replace or resurface same. Additionally, Tenant shall, prior to the expiration or sooner termination of this Lease, remove any improvements installed by Tenant (other than the initial tenant improvements install pursuant to Exhibit F) and repair all damage caused by such removal, unless Landlord, at the time it consented to such improvements waived the right to require such removal. If the Leased Premises are not surrendered to Landlord in the condition required by this Article at the expiration or sooner termination of this Lease, Landlord may, at Tenant’s expense, so remove Tenant’s signs, property and/or improvements not so removed and make such repairs and replacements not so made or hire, at Tenant’s expense, independent contractors to perform such work. Tenant shall be liable to Landlord for all costs incurred by Landlord in returning the Leased Premises to the required condition, plus interest on all costs incurred from the date paid by Landlord at the then maximum rate of interest not prohibited by Law until paid, payable by Tenant to Landlord within ten days after receipt of a statement therefore from Landlord, and Tenant shall be deemed to have impermissibly held over until such time as such required work is completed, and Tenant shall pay Base Monthly Rent and Additional Rent in accordance with the terms of Section 13.2 (Holding Over) until such work is completed. Tenant shall indemnify Landlord against loss or liability resulting from delay by Tenant in so surrendering the Leased Premises, including, without limitation, any claims made by any succeeding tenant or any losses to Landlord due to lost opportunities to lease to succeeding tenants.
