Contractor Certification regarding Business with Certain Countries and Organizations Pursuant to Subchapter F, Chapter 2252, Texas Government Code], Contractor certifies Contractor is not engaged in business with Iran, Sudan, or a foreign terrorist organization. Contractor acknowledges this Agreement may be terminated and payment withheld if this certification is inaccurate.
Changes Forbidden without Consent of Owner Neither the Design Professional nor the Contractor shall make any change whatsoever in the work without an approved Change Order. In the absence of an approved Change Order, the Contractor shall have no claim for payment, repayment, reimbursement, remittance, remuneration, compensation, profit, cost, overhead, expense, loss, expenditure, allowance, charge, demand, hire, wages, salary, tax, cash, assessment, price, money, xxxx, statement, dues, recovery, restitution, benefit, recoupment, exaction, injury, damages, or time based upon or resulting from any change. The provisions of this Article do not apply to emergencies as described in Article 1.4.4.
Certification Regarding Business with Certain Countries and Organizations Pursuant to Subchapter F, Chapter 2252, Texas Government Code, PROVIDER certifies it is not engaged in business with Iran, Sudan, or a foreign terrorist organization. PROVIDER acknowledges this Purchase Order may be terminated if this certification is or becomes inaccurate.
Movement of Natural Persons 1. This Article applies to measures affecting natural persons who are service suppliers of a Party, and natural persons of a Party who are employed by a service supplier of a Party, in respect of the supply of a service.
Class, Collective and Representative Action Waiver THE PARTIES AGREE THAT COVERED CLAIMS WILL, AT EITHER PARTY’S ELECTION, ONLY BE ARBITRATED ON AN INDIVIDUAL BASIS AND THAT EACH WAIVES THE RIGHT TO PARTICIPATE IN OR RECEIVE COMPENSATION FROM ANY CLASS, COLLECTIVE OR REPRESENTATIVE PROCEEDING. NO PARTY MAY BRING A CLAIM ON BEHALF OF OTHER INDIVIDUALS; ANY ARBITRATOR HEARING A COVERED CLAIM MAY NOT COMBINE MORE THAN ONE INDIVIDUAL’S CLAIM OR CLAIMS INTO A SINGLE CASE OR TO ARBITRATE ANY FORM OF A CLASS, COLLECTIVE OR REPRESENTATIVE PROCEEDING. SHOULD ANY PORTION OF THE FOREGOING WAIVER BE FOUND INVALID, THE REMAINING PORTION THAT IS VALID WILL BE ENFORCED TO THE FULLEST EXTENT ALLOWED BY APPLICABLE LAW.
Appointment of Key Sub-Contractors The Supplier shall ensure that all Sub-Contracts contain a provision: requiring the Supplier to pay any undisputed sums which are due from it to the Sub-Contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice; requiring that any invoices submitted by a Sub-Contractor shall be considered and verified by the Supplier in a timely fashion and that undue delay in doing so shall not be sufficient justification for failing to regard an invoice as valid and undisputed; requiring the Sub-Contractor to include in any Sub-Contract which it in turn awards suitable provisions to impose, as between the parties to that Sub-Contract, requirements to the same effect as those required by sub-clauses 5.17.1 and 5.17.2 directly above; and conferring a right to the Customer to publish the Supplier’s compliance with its obligation to pay undisputed invoices within the specified payment period. The Supplier shall pay any undisputed sums which are due from it to a Sub-Contractor within thirty (30) days from the receipt of a valid invoice. Any invoices submitted by a Sub-Contractor to the Supplier shall be considered and verified by the Supplier in a timely fashion. Undue delay in doing so shall not be sufficient justification for the Supplier failing to regard an invoice as valid and undisputed. Notwithstanding any provision of Clauses 9.2 (Confidentiality) and 13 (Publicity, Media and Official Enquiries) if the Supplier notifies the Customer that the Supplier has failed to pay an undisputed Sub-Contractor’s invoice within thirty (30) days of receipt, or the Customer otherwise discovers the same, the Customer shall be entitled to publish the details of the late or non-payment (including on Government websites and in the press).
Waivers and Supplemental Agreements with Consent of Holders With the consent of the Holders of Certificates of each Class representing Certificate Balances aggregating not less than 66% of the related Class Balance, (i) compliance by Xxxxxx Xxx with any of the terms of this Trust Agreement may be waived or (ii) Xxxxxx Mae, in its corporate capacity and in its capacity as Trustee, may enter into any Supplemental Agreement for the purpose of adding any provisions to or changing in any manner or eliminating any of the provisions of this Trust Agreement or of modifying in any manner the rights of the Holders of the Certificates issued under this Trust Agreement; provided, however, that no such waiver or Supplemental Agreement shall:
Dealings with Public Servants Contractor has not given, has not offered to give, and does not intend to give at any time hereafter any economic opportunity, future employment, gift, loan, gratuity, special discount, trip, favor, or service to a public servant in connection with this Contract or any related Solicitation, or related Solicitation Response.
PROHIBITION ON CONTRACTS WITH COMPANIES BOYCOTTING ISRAEL CERTIFICATION As required by Chapter 2271 of the Texas Local Government Code the Contractor must verify that it 1) does not boycott Israel; and 2) will not boycott Israel during the term of the Contract. Pursuant to Section 2271.001, Texas Government Code:
PUBLIC CONTRACTS WITH NATURAL PERSONS 24-76.5-101, et seq., C.R.S. Contractor, if a natural person eighteen (18) years of age or older, hereby swears and affirms under penalty of perjury that Contractor (i) is a citizen or otherwise lawfully present in the United States pursuant to federal law, (ii) shall comply with the provisions of §§24-76.5-101, et seq., C.R.S., and (iii) has produced one form of identification required by §24-76.5-103, C.R.S. prior to the Effective Date of this Contract.